M/s. Vijay Durgambiga Construction v. The District Collector
Case brief
What is this about?
Madras High Court Madurai Bench; W.P.(MD)No.5271 of 2026 with W.M.P(MD)Nos.4413 & 4414 of 2026; decided 27.02.2026 by Justice R.VIJAYAKUMAR. Petitioner: M/s.Vijay Durgambiga Construction (Partner N.Manoj), counsel M/s.V.Meenakshi Sundaram for M/s.S.Vashik Ali. Respondents: District Collector, Project Director DRDA and Executive Engineer, Tirunelveli, through Special Government Pleader M/s.D.Farjana Ghoushia. Subject: show cause notice dated 30.01.2026 (received 12.02.2026), Na.Ka. No.A4/3352087/2025, threatening cancellation of rural road work order Work ID No.02/RIDF/2024-25 for missing the January 2026 deadline; delay due to harvest season on agricultural land. Result: time extended to 31.05.2026 via formal order to be passed by respondents; no further extension; petition disposed of, no costs; miscellaneous petitions closed. Statute: Article 226, Constitution of India. No precedents cited.