Allowed¶12

World Window Infrastructure and Logistics Pvt. Ltd. v. Central Warehousing Corporation

Delhi HC18 Jul 2025O.M.P.(MISC.)(COMM.)/535/2025

Case brief

AI extract

What is this about?

O.M.P.(MISC.)(COMM.) 535/2025, High Court of Delhi, Jyoti Singh, J., 18.07.2025; Section 29A(4) and (5) Arbitration and Conciliation Act 1996; extension of arbitrator's mandate; 12-month extension from 18.07.2025; regularization of lapsed period 29.08.2023 to 17.07.2025; CIRP/moratorium-caused delay; Resolution Plan implementation; World Window Infrastructure and Logistics Pvt. Ltd. v. Central Warehousing Corporation; Rohan Builders (India) Pvt. Ltd. v. Berger Paints India Ltd., 2024 SCC OnLine SC 2494 (followed); ICD Loni; claim and counter claim.

What did the court decide?

Extension of the mandate of the Sole Arbitrator by 12 months from 18.07.2025, with regularization of the period between 29.08.2023 and 17.07.2025; petition allowed and disposed of. ¶12

World Window Infrastructure and Logistics Pvt. Ltd. Vs Central… — Arbitration | Delhi HC (2025)

What the court decided

AI extract

Outcome

Extension of the mandate of the Sole Arbitrator by 12 months from 18.07.2025, with regularization of the period between 29.08.2023 and 17.07.2025; petition allowed and disposed of.

¶12

Issue for consideration

Whether sufficient cause exists to extend the mandate of the learned Sole Arbitrator by a period of 12 months under Section 29A(4) and (5) of the Arbitration and Conciliation Act, 1996.

¶1

Ratio / Principle

The Court is satisfied that sufficient cause is made out by the Petitioner for extension of the mandate of the Arbitrator, following the observations of the Supreme Court in Rohan Builders (India) Private Limited v. Berger Paints India Limited.

¶10

Key takeaways

With the consent of the parties, the mandate of the Arbitrator is extended by a period of 12 months from 18.07.2025 and the period between 29.08.2023 to 17.07.2025 is regularized.ratio¶11

Detailed headnote1 paragraphs

Delhi High Court (Jyoti Singh, J.), O.M.P.(MISC.)(COMM.) 535/2025, order dated 18.07.2025: Petition under Section 29A(4) and (5) of the Arbitration and Conciliation Act, 1996 seeking extension of the mandate of the Sole Arbitrator by 12 months. Arbitration arose out of a Contract dated 16.02.2005 (Inland Container Depot, Loni) with rights assigned to WWIL by Tripartite Agreement dated 07.03.2007; protracted litigation over stay/referal of arbitral proceedings preceded completion of pleadings on 06.06.2021. The mandate expired on 28.08.2023 while the Petitioner was undergoing CIRP; after approval and implementation of the Resolution Plan (including acquisition of lender debts by Prudent ARC Limited and change of ownership to M/s Thrivehill Realtors Private Limited via Security Purchase Agreement dated 10.10.2024), the Petitioner sought revival in 2025. The Respondent did not object but requested a direction that the Arbitrator adjudicate the claim and counter claim simultaneously. Following the observations of the Supreme Court in Rohan Builders (India) Pvt. Ltd. v. Berger Paints India Ltd., 2024 SCC OnLine SC 2494, the Court found sufficient cause and, with the consent of the parties, extended the mandate by 12 months from 18.07.2025, regularized the period 29.08.2023 to 17.07.2025, and allowed/disposed of the petition.

¶1

$~9

¶2

IN THE HIGH COURT OF DELHI AT NEW DELHI

¶3

- O.M.P.(MISC.)(COMM.) 535/2025

¶4

WORLD WINDOW INFRASTRUCTURE AND LOGISTICS PVT. LTD. .....Petitioner Through: Mr. Nilav Bandopadhyay and Mr. Ankur Mishra, Advocates.

¶5

versus

¶6

CENTRAL WAREHOUSING CORPORATION .....Respondent Through: Mr. A.K. Ganguli, Sr. Advocate with Mr. Shaiwal Srivastava, Mr. Arunabha Ganguli, Mr. Nilesh Sharma, Ms. Awantika Manohar and Ms. Parul Dhuruey, Advocates.

¶7

CORAM:

¶8

HON'BLE MS. JUSTICE JYOTI SINGH

¶9

O R D E R

¶10

% 18.07.2025

¶11

This petition is filed on behalf of the Petitioner under Section 29A (4) and (5) of the Arbitration and Conciliation Act, 1996 (‘1996 Act’) seeking extension of the mandate of the learned Sole Arbitrator by a period of 12 months.

¶12

A Contract dated 16.02.2005 was executed between Petitioner and Respondent for Strategic Alliance Management and Operation of the Inland Container Depot at Loni, Uttar Pradesh. Based on Petitioner’s request, a Tripartite Agreement was executed on 07.03.2007 between Petitioner, Respondent and WWIL, pursuant to which all rights, interests and obligations for performing the Contract dated 16.02.2005 were transferred/assigned to WWIL. Disputes having arisen between the parties,

¶13

O.M.P.(MISC.)(COMM.) 535/2025

¶14

Page 1 of 4

¶15

This is a digitally signed order.

¶16

The authenticity of the order can be re-verified from Delhi High Court Order Portal by scanning the QR code shown above. The Order is downloaded from the DHC Server on 22/07/2025 at 12:22:24

¶17

Petitioner invoked Arbitration Clause 21 in the Contract and appointed a Sole Arbitrator on 04.01.2016. Respondent filed its Statement of Claim and Petitioner raised jurisdictional issues and also filed a civil suit seeking inter alia stay of arbitral proceedings in which Respondent filed application under Section 8 of 1996 Act. Learned Civil Judge allowed the application of the Petitioner under Order XXXIX Rules 1 and 2 CPC and stayed the arbitral proceedings on 15.02.2016.

¶18

It is stated in the petition that vide order dated 15.03.2016, the Civil Judge dismissed the application under Section 8. Respondent filed first appeals before the District Judge Ghaziabad challenging orders dated 15.02.2016 and 15.03.2016. Writ petitions were filed before the Allahabad High Court for direction to the District Judge to decide the appeals expeditiously, which the Court declined to do and Respondent approached the Supreme Court. By order dated 12.12.2017, the Supreme Court directed the District Judge to decide the appeals within a time bound manner. District Judge, Ghaziabad allowed the appeals of the Respondent and directed the matter to be referred to ongoing arbitration, which was unsuccessfully challenged upto the Supreme Court.

¶19

It is further stated that Petitioner filed ARB.P. 437/2018 under Section 11(6) of 1996 Act on 25.05.2018 seeking appointment of Sole Arbitrator and termination of mandate of the Arbitrator. Another petition being O.M.P. (T)(COMM) 45/2018 was filed on 29.05.2018 for termination of the mandate of the Arbitrator, which was dismissed on 14.08.2018 and being aggrieved, Petitioner approached the Supreme Court, where both parties agreed to appoint another Sole Arbitrator.

¶20

O.M.P.(MISC.)(COMM.) 535/2025

¶21

Page 2 of 4

¶22

This is a digitally signed order.

¶23

The authenticity of the order can be re-verified from Delhi High Court Order Portal by scanning the QR code shown above. The Order is downloaded from the DHC Server on 22/07/2025 at 12:22:24

¶24

On 12.11.2018, Respondent sought extension of the mandate of the Arbitrator in O.M.P.(MISC.)(COMM.) 342/2018, which was disposed of on 06.03.2019 directing that fresh arbitration would commence from the date the new Arbitrator entered upon reference. Pleadings were completed on 06.06.2021, however, the arbitral proceedings were adjourned from time to time in light of the fact that moratorium was issued against the Petitioner.

¶25

Learned counsel for the Petitioner submits that mandate of the Arbitrator expired on 28.08.2023 and arbitral proceedings are at the stage of evidence of the Petitioner, which is the Counter Claimant before the Arbitrator. It is explained that the Petitioner has approached this Court in 2025 for extension of the mandate, owing to the reason that on 28.08.2023 when the mandate expired, Petitioner was undergoing CIRP proceedings and arbitral proceedings had to be deferred. However, subsequently the Resolution Plan was approved and the Successful Resolution Applicant (‘SRA’) proceeded to implement the plan and as a part of implementation, Prudent ARC Limited acquired the debts of the existing lenders in accordance with the approved Plan. New Board of Directors was constituted, which process was completed in September, 2024. It is further pointed out that there was an additional change in the ownership of the Petitioner, which was transferred to M/s Thrivehill Realtors Private Limited and a Security Purchase Agreement dated 10.10.2024 was executed between SRA and RKG Fund I. As a result, new Board of Directors was appointed in December, 2024. In light of these facts, Petitioner has now approached the Court for extension of mandate of the Sole Arbitrator with due intimation to the Arbitrator for the revival of the arbitral proceedings.

¶26

Issue notice.

¶27

O.M.P.(MISC.)(COMM.) 535/2025

¶28

Page 3 of 4

¶29

This is a digitally signed order.

¶30

The authenticity of the order can be re-verified from Delhi High Court Order Portal by scanning the QR code shown above. The Order is downloaded from the DHC Server on 22/07/2025 at 12:22:24

¶31

Mr. Shaiwal Srivastava, learned counsel accepts notice on behalf of the Respondent.

¶32

Learned Senior Counsel appearing on behalf of the Respondent fairly and candidly does not object to the extension of mandate of the Arbitrator but submits that direction be issued to the learned Arbitrator to adjudicate both the Claim and the Counter Claim of the parties simultaneously. 10. Having heard learned counsel for the Petitioner and on perusal of the documents appended to the petition, this Court is satisfied that sufficient cause is made out by the Petitioner for extension of the mandate of the Arbitrator following the observations of the Supreme Court in Rohan Builders (India) Private Limited v. Berger Paints India Limited, 2024 SCC OnLine SC 2494.

¶33

Accordingly, with the consent of the parties, mandate of the Arbitrator is extended by a period of 12 months from 18.07.2025 and period between 29.08.2023 to 17.07.2025 is regularized.

¶34

Petition is allowed and disposed of in the aforesaid terms.

¶35

JYOTI SINGH, J

¶36

JULY 18, 2025 S.Sharma

¶37

O.M.P.(MISC.)(COMM.) 535/2025

¶38

Page 4 of 4

¶39

This is a digitally signed order.

¶40

The authenticity of the order can be re-verified from Delhi High Court Order Portal by scanning the QR code shown above. The Order is downloaded from the DHC Server on 22/07/2025 at 12:22:24

Procedural history

How this case reached the court

AI extract

Prior proceeding
Contract dated 16.02.2005 executed between Petitioner and Respondent for Strategic Alliance Management and Operation of the Inland Container Depot at Loni, Uttar Pradesh.¶2
Prior proceeding
Tripartite Agreement dated 07.03.2007 between Petitioner, Respondent and WWIL transferring/assigning all rights, interests and obligations under the Contract to WWIL.¶2
Prior proceeding
Petitioner invoked Arbitration Clause 21 of the Contract and appointed a Sole Arbitrator on 04.01.2016.¶2
Prior proceeding
Respondent filed an application under Section 8 of the 1996 Act in the civil suit; Civil Judge allowed Petitioner's application under Order XXXIX Rules 1 and 2 CPC and stayed the arbitral proceedings on 15.02.2016.¶2
Prior proceeding
By order dated 15.03.2016 the Civil Judge dismissed the application under Section 8.¶3
Prior proceeding
Respondent filed first appeals before the District Judge, Ghaziabad challenging orders dated 15.02.2016 and 15.03.2016.¶3
Prior proceeding
Writ petitions filed before the Allahabad High Court seeking directions for expeditious disposal of the appeals; the Court declined; Respondent approached the Supreme Court, which on 12.12.2017 directed the District Judge to decide the appeals within a time-bound manner.¶3
Prior proceeding
District Judge, Ghaziabad allowed Respondent's appeals and directed referral to ongoing arbitration; challenge failed up to the Supreme Court.¶3
Prior proceeding
Petitioner filed ARB.P. 437/2018 under Section 11(6) of the 1996 Act on 25.05.2018 seeking appointment of Sole Arbitrator and termination of mandate of the Arbitrator.¶4
Prior proceeding
O.M.P.(T)(COMM) 45/2018 filed on 29.05.2018 for termination of the Arbitrator's mandate was dismissed on 14.08.2018; in the Supreme Court both parties agreed to appoint another Sole Arbitrator.¶4
Prior proceeding
On 12.11.2018 Respondent sought extension of the mandate in O.M.P.(MISC.)(COMM.) 342/2018, disposed of on 06.03.2019 directing fresh arbitration to commence from the date the new Arbitrator entered upon reference.¶5
Prior proceeding
Pleadings completed on 06.06.2021; proceedings adjourned from time to time owing to moratorium issued against the Petitioner.¶5
Prior proceeding
Mandate expired on 28.08.2023 while proceedings were at the stage of evidence of the Petitioner (Counter Claimant).¶6
Prior proceeding
Delay attributed to CIRP proceedings of the Petitioner commencing around expiry of the mandate; Resolution Plan subsequently approved and implemented, with Prudent ARC Limited acquiring debts of existing lenders.¶6
Prior proceeding
Additional change in ownership: transfer to M/s Thrivehill Realtors Private Limited and Security Purchase Agreement dated 10.10.2024 between SRA and RKG Fund I; new Board of Directors appointed in December 2024.¶6

World Window Infrastructure and Logistics Pvt. Ltd. v. Central Warehousing Corporation

Case brief

What is this about?

What did the court decide?

World Window Infrastructure and Logistics Pvt. Ltd. v. Central Warehousing Corporation

Case brief

What is this about?

What did the court decide?

Why is it important?

What the court decided

Issues for consideration

Cases cited

Statutes considered

Procedural history

Parties & counsel

Coram

Case details

Similar cases

Talwar Cars Private Limited Vs Volvo Auto India Private Limited

Power Hf India Private Limited through Its Authorised Representataive Mr. Harish Prabhakar Jere Vs Perfect Diesel Sales and Service through Its Proprietor Mr. Prabir Kumar Chakraborty & Anr.

M/S National Skill Development Corporation (Nsdc) Vs Iht Network Limited & Ors.

Ratnagiri Gas and Power Private Limited Vs National Insurance Company Limited

Shipra Hotels Limited Vs Indiabulls Housing Finance Ltd. & Anr.

Shipra Estate Limited Vs Indiabulls Housing Finance Ltd. & Anr.

Dee Vee Projects Ltd. Vs Hindustan Urvarak and Rasayan Ltd.

M/S Shivhare Roadlines Vs Container Corporation of India Ltd.

Talwar Cars Private Limited Vs Volvo Auto India Private Limited

Seema & Anr. Vs State & Anr.

Power Hf India Private Limited through Its Authorised Representataive Mr. Harish Prabhakar Jere Vs Perfect Diesel Sales and Service through Its Proprietor Mr. Prabir Kumar Chakraborty & Anr.

Axis Trustee Services Limited Vs Mr. Rahul Yadav and Anr.

Iffco Kisan Finance Ltd. Vs Action Construction Equipment Ltd.

M/S Simplex Infrastructures Ltd. Vs National Highways Authority of India & Anr.