Dismissed

Shambhavi Contractors (Pvt.) Ltd. v. M/S National Buildings Contruction Corporation Limited and Ors.

Delhi HC9 Feb 2016W.P.(C)/1047/2016

Case brief

AI extract

What is this about?

Petitioner sought quashing of contract termination citing delays caused by respondents. Court held petition barred by long delay, laches, and serious disputed questions of fact involving third-party rights.

What did the court decide?

Writ petition and accompanying application dismissed without interference as delay was unreasonable and third-party rights created.

Shambhavi Contractors (Pvt.) Ltd. Vs M/S… — Contract and Commercial Disputes | Delhi HC (2016)

¶1

¶2

IN THE HIGH COURT OF DELHI AT NEW DELHI

¶3

- W.P.(C) 1047/2016 & C.M.No.4570/2016

¶4

SHAMBHAVI CONTRACTORS (PVT.) LTD ..... Petitioner

¶5

Through Mr.Vishal K. Panwar, Advocate.

¶6

versus

¶7

M/S NATIONAL BUILDINGS CONTRUCTION CORPORATION LIMITED AND ORS ..... Respondents Through

¶8

Date of Decision: 09^th February, 2016

¶9

CORAM: HON'BLE MR. JUSTICE MANMOHAN

¶10

J U D G M E N T

¶11

MANMOHAN, J: (Oral)

¶12

Present writ petition has been filed seeking quashing of termination of the contract dated 4^th May, 2012, whereby the contract of the petitioner for rehabilitation, restrengthening, remodelling retrofitting, renovation and interior decoration of existing building of Allahabad Bank Building situated at A-17, Parliament Streets, New Delhi – 110 001 was terminated on the ground of delay in completion of work.

¶13

In the petition, it has been averred that delay in completion of work was attributable to the respondent as the site was not made available to the petitioner within time and also payments were not released in a timely manner.

¶14

W.P.(C) No.1047/2016

¶15

Page 1 of 3

¶16

This Court has perused the writ petition and finds that it entails serious disputed question of facts.

¶17

Court is also of the view that the present writ petition is barred by delay and laches as the termination of the contract took place more than three years back.

¶18

In State of Madhya Pradesh and another Vs. Bhailal Bhai & Anr., AIR 1964 SC 1006, the Supreme Court has held as under:-

¶19

“ ........Learned Counsel is right in his submission that the provisions of the Limitation act do not as such apply to the granting of relief under Art.226. It appears to us however that the maximum period fixed by the legislature as the time within which the relief by a suit in a civil court must be brought may ordinarily be taken to be a reasonable standard by which delay in seeking remedy under Art.226 can be measured. This Court may consider the delay unreasonable even if it is less than the period of limitation prescribed for a civil action for the remedy but where the delay is more than this period, it will almost always be proper for the Court to hold that it is unreasonable.....”

¶20

The Supreme Court in Banda Development Authority, Banda Vs. Moti Lal Agarwal & Ors., (2011) 5 SCC 394 has held as under:-

¶21

“ 17. It is true that no limitation has been prescribed for filing a petition under Article 226 of the Constitution but one of the several rules of self-imposed restraint evolved by the superior courts is that the High court will not entertain petitions filed after long lapse of time because that may adversely affect the settled/crystallised rights of the parties. If the writ petition is filed beyond the period of limitation prescribed for filing a civil suit for similar cause, the High Court will treat the delay unreasonable and decline to entertain the grievance of the petitioner on merits.”

¶22

( emphasis supplied )

¶23

W.P.(C) No.1047/2016

¶24

Page 2 of 3

¶25

Since third party right has been created and the risk purchase contractor has admittedly been appointed to complete the balance contract, this Court is of the view that no interference is called for in the present writ petition and the same along with the application is accordingly dismissed.

¶26

MANMOHAN, J

¶27

FEBRUARY 09, 2016 KA

¶28

W.P.(C) No.1047/2016

¶29

Page 3 of 3

Shambhavi Contractors (Pvt.) Ltd. v. M/S National Buildings Contruction Corporation Limited and Ors.

Case brief

What is this about?

What did the court decide?

Shambhavi Contractors (Pvt.) Ltd. v. M/S National Buildings Contruction Corporation Limited and Ors.

Case brief

What is this about?

What did the court decide?

What the court decided

A compact analysis

Issues for consideration

Cases cited

Parties & counsel

Coram

Case details

Similar cases

Maya Devi Vs Government of NCT of Delhi & Ors.

Jamilur Rahman Ansari Vs Guru Gobind Singh Indraprastha University

Aurobindo Pharma Ltd. Vs Union of India & Ors.

Phuntsok Wangyal Vs Ministry of External Affairs & Anr.

Tanmayee Ranjan Vs the Oriental Insurance Company Ltd. and Anr.

L.S. Vaswani Vs the Registrar, Co-Operative Societies

Jagjeet Impex & Ors. Vs Principal Commissioner of Customs & Ors.

Kunal Ranjan Singh & Ors. Vs Union of India & Ors.

Jamilur Rahman Ansari Vs Guru Gobind Singh Indraprastha University

Aurobindo Pharma Ltd. Vs Union of India & Ors.

Phuntsok Wangyal Vs Ministry of External Affairs & Anr.

Delhi Tax Bar Association Vs Union of India & Ors.

Prakash Punj Vidya Sadan School Vs Directorate of Education

Kirti Azad & Ors. Vs Delhi District Cricket Association & Ors.