SRS J W.P.Nos.802 and 14051 of 2025 issues, requesting the respondents to arrange sand by letters dated 28.09.2024, 04.10.2024, 02.11.2024, 11.11.2024 and 15.11.2024, by which time the Extension of Agreement Time (BOAT) was completed by 30.04.2024. 9. As the matter stood thus, the 3'"'^ respondent submitted a proposal to the 2"'^ respondent by letter dated 03.11.2024, to cancel the agreement. The petitioners, being aware of the said proposal, submitted a representation dated 07.11.2024, requesting further time up to 31.03.2025, without imposition of liquidated damages. 10. By the proceedings impunged in W.P.No.802 of 2025, the contract was determined. The committee, consisting of respondents 1, 2, 5 and the Executive Director, TCR & TM resolved to determine the contract and to finalise new tenders for completion of the balance work. Thereafter, the respondent floated fresh tenders for the balance work vide DIPR RO NO.15049/CL/ADVT/1/1/2021-22 dated 06.01.2025. 11. The petitioner firm made a representation dated 10.01.2025, in pursuance of the order in W.P.No.802 of 2025 dated 09.01.2025 and sought time up to 30.09.2025 without liquidated damages. The 3'^'^ respondent sent a 2"^ Extension of Agreement Time (BOAT) proposal to the Engineer-in-Chief detailing the entire developments, also submitted a calculation sheet with detailed liquidated damages, arrived at Rs. 1,15,37,568/vide letter dated 02.03.2025 under intimation to the petitioners. The 4*'' respondent also submitted a detailed report to the O'"' respondent concerning the measurement of work done by the petitioner firm and the price to be payable to the petitioner firm in compliance with the interim order dated 09.01.2025 in W.P.No.802 of 2025. Based on the executed quantities, the value of the work completed was assessed at Rs.8,60,89,958/-, while the value as per the schedule of payment stands at Rs.8,70,19,075/-. After applying the requisite statutory deductions to the schedule of payment amount, the net payable amount to the contractor was arrived at Rs.7,98,14,651/-, out of which Rs.7,86,80,764/-, was already ■•Vi"
