M/S. Duro Felguera, S. a. versus M/S. Gangavaram Port Limited

Arbitration and Conciliation (Amendment) Act, 2015: ss. 11 (6) and 11 (6A) - GPL awarded tender work to applicant-Foreign company and FGJ-its lndian subsidiary - Later original contract c split into five different and separate packages with different job description - One contract with the applicant and four with FGl - Each contract had separate arbitration clause - Dispute between parties - Arbitration clause invoked - FGJ issued four arbitration notices, applicant issued one arbitration notice whereas GPL issued comprehensive arbitration notice consisting single arbitral tribunal D oi1 basis of MoU - Whether there has to be a single arbitral tribunal for International Commercial Arbitration or Multiple Arbitral Tribunals - Held: Since the dispute between the parties arose in 2016, the instant issue is governed by the amended provision of s. 11 (6A) as per which the power of the court is con.fined only to E examine the existence of the arbitration agreement - On facts, there are five separate Letters of Award; five separate contracts awarded to applicant and FGJ; separate suliject matters; separate and distinct work; each containing separate arbitration clause signed by the respective parties to the contract - Original Package split into five different Packages, each having different works prima facie F indicates the intention of the parties to split-up Original Package into jive different packages - Thus, when there are five separate contracts, one with foreign company and four with Indian subsidiary, each having independei1t existence with separate arbitration clauses, and Corporate Guarantee also contains an arbitration clause, there G cannot be a single arbitral tribunal for "International Commercial Arbitration".

¶11

c

¶12

G

¶13

Disposing of the matters, the Court

¶14

HELD: Per Banumathi, J.:

¶15

1.1 As per the amended provision of sub-section (6A) of H 285

¶16

286

¶17

[2017] 10 S.C.R.

¶18

SUPREME COURT REPORTS

¶19

A Section 11 of the Arbitration and Conciliation (Amendment) Act, 2015(Act 3 of 2016), the power of the court is confined only to examine the existence of the arbitration agreement. It further clarifies that the decision of appointment of an arbitrator will be made by the Supreme Court or the High Court (instead of Chief Justice) and under Section 11(7), no appeal shall lie against such B an appointment. The language in Section 11(6) of the Act "the Chief Justice or any person or institution designated by him" has been substituted by "Supreme Court or as the case may be the High Court or any person or institution designated b.v such Court". As per sub-section (6A) of Section 11, the power of the Court c has now been restricted only to see whether there exists an arbitration agreement. The amended provision in sub-section (7) of Section ll provides that the order passed under Section 11(6) shall not be appealable and thus, finality is attached to the order passed under this Section. [Paras 13, 17] [299-H; 300-A-B; 301D D-EJ

¶20

l.2 There is no dispute between the parties that the issue at hand is governed by the amended pro,ision of sub-section (6A) of Section 11. Even though Letters of .\ward are dated 17.03.2012 and five separate contracts were enterl:'d into between the parties on 10.05.2012, the dispute arose between the parties E in 2016, GPL invoked the Bank Guarantee on 07.01.2016 and the applicant and its Indian Subsidiary-FGI issued notice of dissatisfaction on 04.02.2016 and 07.02.2016 respectively to GPL The applicant issued arbitration notice on 05.04.2016 for contract relating to Package No. 4 and FGI issued four arbitration notices F dated 07.04.2016 for contracts relating to Packages No. 6 to 9. GPL also issued an arbitration notice on 13.04.2016. Since the dispute between the parties arose in 2016, the amended provision of sub-section (6A) of Section 11 would govern the issue, as per which the power of the Court is confined only to examine the existence of the arbitration agreement. ll'ara 191 [306-E-Gl

¶21

G

¶22

l.3 Original Package No.4 Tender Document for GPL Expansion-2011 consisted of "Bulk Materiul Handling Systems including Engineering, Design, Procurement of Materials, Manufacturing, Supply erection, testing and commissioning of bulk material handling systems including all other associated works and H integration of the same with the existing coal handling systems

¶23

MIS. DURO FELGUERA, S. A. v. M/S. GANGAVARAM PORT 287 LIMITED

¶24

(Package 4-"Works'J. By mutual consent and agreement of the A parties, Original Package No.4 TD was split into five different Packages-New Package No. 4 (awarded to the applicant (Spanish Company)] and Packages No. 6, 7, 8 and 9 awarded to its Indian subsidiary-FGI. Letters of Award dated 17.03.2012 was awarded to the applicant and FGI for various Packages. Pursuant to Letters B of Award, parties have entered into contract agreement on 10.05.2012. There are five separate Letters of Award; five separate Contracts; separate subject matters; separate and distinct work; each containing separate arbitration clause signed by the respective parties to the contract. All the five contracts awarded to the applicant and FGI have independent arbitration c clauses. The Original Package No. 4 TD split into five different Packages, each having different works prima facie indicates the intention of the parties to split-up original Package No. 4 TD into . five different packages. [Paras 20-23] [307-A-C; 308-E-G; 310A-B]

¶25

c

¶26

D

¶27

1.4 In the contract agreement, the parties have agreed that the documents mentioned in clause (2) of the agreement will have priority. Clauses as to the priority of the documents was incorporated in all other contract agreements-Package No. 4 awarded to the applicant, Packages No. 6, 7, 8 and 9 awarded to E Indian subsidiary FGI. In the sequence of documents of clause (2) of the contract agreement, the Tender Document is mentioned in the sequence only as (g) and all other documents or the other documents like Letters of Award, Special conditions of contract etc. have priority over the same. While so, the terms contained in Original Package No. 4 TD including the arbitration clause F cannot have priority over the Special Conditions of contract of the split-up contracts. When the Original Package No. 4 TD has been split-up into five different Packages, GPL is not right in contending that inspite of split-up of the work, the Original Package No.4 TD collectively covered all the five Packages. After the Original Package No. 4. was split into five different contracts, G the parties cannot go back to the. Original Package No.4 nor can they merge them into one·. It cannot be said that sub-clause 20.6 of the Original Package No. 4 TD will still collectively cover all the five Packages to justify constitution of single Arbitral Tribunal. (Para 24] (310-B-C, F-H; 311-A] H

¶28

H

¶29

288

¶30

SUPREME COURT REPORTS

¶31

[2017] IO S.C.R.

¶32

A 1.5 The foreign company-applicant had executed a Corporate Guarantee dated 17.03.2012 guaranteeing the due performance of all the works awarded to the applicant and FGI. The Corporate Guarantee itself has its own separate and distinct arbitration clause. In the Corporate Guarantee, the applicant has undertaken to ensure performance of all the works both by the B applicant and also the contracts pertaining to Packages No. 6 to 9 awarded to FGI. The applicant has also undertaken that in the event of any delay in completion of the works as per the time stipulated for completion of the contracts, the applicant had undertaken to compensate for the delay, damages to GPL which c will be based on the overall contrart price collectively of all the contracts. [Paras 25, 261 (311-B, E-FI

¶33

1.6 As per the terms of Corporate Guarantee, it shall cease on issuance of the performance certificate under all the contracts. Of course, the applicant has given the Corporate Guarantee for D all the five contracts viz., New Package No.4, Packages No. 6 to 9. Corporate Guarantee executed by the applicant dated 17 .03.2012 also recognizes the split up of thl' original Package No. 4 Tender Document. As per the terms of the Corporate Guarantee, it is to be invoked only if breach is established in one of the five contracts. Since the Corporate Guarantee by itself has E a separate arbitration clause, it cannot be contended that by virtue of the Corporate Guarantee executed by the applicant, there has to be a 'composite reference' of 'lnternatio11al Commercial Arbitration' which would cover all the five Packages. The Corporate Guarantee by the applicant cannot supersede the five F split-up contracts and the special conditions of contract thereon. (Para 28] (312-G-H; 313-A-B]

¶34

l. 7 The applicant and FGI have executed a tripartite Memorandum of Understanding (Mou) on 11.08.2012 which, according to GPL, covers all the five l'Ontracts namely New G Package No. 4, Package No. 6, Package No. 7, Package No. 8 and Package No. 9. In the said MoV both the applicant and FGI have agreed to carry out the works as per the priority of the documents listed therein which includes the Original Package No.4 Tender Document issued and final bid submitted by the applicant and FGI. [Para 29] [313-B-C]

¶35

H

¶36

M/S. DURO FELGUERA, S. A. v. M/S. GANGAVARAM PORT 289 LIMITED

¶37

l.8 As per Section 7(5) of the Act, even though the contract A between the parties does not contain a provision for arbitration, an arbitration clause contained in an independent document will be imported and engrafted in the contract between the parties, by reference to such independent document in the contract, if the reference is such as to make the arbitration clause in such B document, a part of the contract. Section 7(5) requires a conscious acceptance of the arbitration clause from another document, as a part of their contract, before such arbitration clause could be read as a part of the contract between the parties. The question whether or not the arbitration clause contained in another document, is incorporated in the contract, is always a question of C construction of document in reference to intention of the parties. The terms of a contract may have to be ascertained by reference to more than one document. [Para 33] [315-D-.E]

¶38

l.9 In the MoU, Original Package No.4 Tender Document is merely referred only to have more clarity on technical and D execution related matters and the parties agreed that the works shall be carried out as per the priority of the documents indicated thereon. Mere reference to Original Package No.4 Tender Document in the sequence of priority of documents (as serial No.4) indicates that the documents Original Package No. 4 TD E containing arbitration clause was not intended to be incorporated · in its entirety but only to have Clarity in priority of the documents in execution of the work. Original Package No.4 TD occurs as Serial No.4 in sequence, after three other documents. There are a number of contract agreements between the parties - GPL, petitioner company and FGI. MoU dated 11.08.2012 itself does F not contain an arbitration clause. When reference is made to the priority of documents to have clarity in execution of the work, such general reference to Original Package N o.4 Tender Document will not be sufficient to hold that the arbitration clause 20.6 in the Original Package No.4 TD is incorporated in the MoU. G [Para 35) [317-G-H; 318-A, C-D)

¶39

G

¶40

1.10 As per the amended provision of sub-section (6A) of Section 11, the power of the court is only to examine the existence of arbitration agreement. When there are five separate contracts each having independent existence with separate arbitration

¶41

H

¶42

290

¶43

SUPREME COURT REPORTS

¶44

[2017] lO S.C.R.

¶45

A clauses that is New Package No.4 (with foreign company) and Packages No. 6, 7, 8 and 9 [with Indian subsidiary (FGI)) based on MoU and C_orporate Guarantee, there cannot be a single arbitral tribunal for "lllternational Commercia/Arbitratio11". [Para 361 [318-E-FJ

¶46

B l.ll The Corporate Guarantee dated 17.03.2012 was executed by the foreign company undertaking to compensate for the delay, damages to the GPL. Since the Corporate Guarantee was by the foreign company which contains separate arbitration clause, there has to be a separate arbitral tribunal for resolving C the disputes arising out of the said Corporate Guarantee. [Para 38J (319-B)

¶47

1.12 New Package No. 4 TD- F.O.B. Supply of Bulk Material Handling Equipments USD 26,666,932 has been awarded to the foreign company-petitioner company. Since it is a foreign company, in so far as the contract awarded to the petitioner D company i.e. New Package No.4 and the dispute arising out of the Corporate Guarantee executed by the foreign company is concerned, the arbitral tribunal has to be for the international commercial arbitration. [Para 39) [319-C)

¶48

1.13 In the instant case, all five different Packages as well E as the Corporate Guarantee have separate arbitration clauses and they do not depend on the terms and conditions of the Original Package No.4 TD nor on the MoU, which is intended to have clarity in execution of the work.[Para 40] (319-G-H; 320-A)

¶49

Chloro Contmls India Private ltd. v. Severn Trent Water

¶50

F Purification Inc. and Ors. (2013) 1 SCC 641 : (20121 13 SCR 402 - distinguished.

¶51

1.14 The petitioner company being a foreign company, for each of the disputes arising under New Package No.4 and Corporate Guarantee, International Commercial Arbitration G Tribunal are to be constituted. The petitioner has nominated Justice D.R. Deshmukh, Former Judge of Chhattisgarh High Court as their arbitrator. GPL has nominated Justice M. N. Rao, Former Chief Justice of Himachal Pradesh High Court. Alongwith the above two arbitrators Mr. Justice R.M. Lodha, Former Chief

¶52

H

¶53

MIS. DURO FELGUERA, S. A. v. MIS. GANGAVARAM PORT LIMITED

¶54

291

¶55

Justice of India is appointed as the Presiding Arbitrator of the A International Commercial Arbitral Tribunal. [Para 41] [320-.B-C]

¶56

1.15 Package No.6 (Rs.208,66,53,657/-); Package No.7 (Rs.59,14,65,706/-); Package No.8 (Rs.9,94,38,635/-); and Package No.9 (Rs.29,52,85, 558/-) have been awarded to the Indian company-FGI. Since the issues arising between the parties B are inter-related, the same arbitral tribunal, Justice R.M. Lodha, Former Chief Justice of India, Justice D.R. Deshmukh, Former Judge of Chhattisgarh High Court and Justice M. N. Rao, Former Chief Justice of Himachal Pradesh High Court, shall separately constitute Domestic Arbitral Tribunals for resolving each of the disputes pertaining to Packages No.6, 7, 8 and 9. [Para 42] [320C D-E]

¶57

C

¶58

Konkan Railway Corpn. Ltd. and Ors. v. Mehu/ Construction Co. (2000) 7 SCC 201 : [2000] 2 Suppl. SCR 563; Konkan Railway Corpn. Ltd. & Am:. v. Rani Construction Pvt. Ltd. (2002) 2 SCC 388 : [2009) 10 SCR 373; S.B.P & Co v. Patel Engineering Ltd and Anr. (2005) 8 SCC 618 : [2005) 4 Suppl. SCR 688; National Insurance Company Limited v. Boghara Pol;jab Private Limited (2009) 1 SCC 267 : [2008) 13 SCR 638; Shree Ram Mills Ltd. v. Utility Premises (P) Ltd, (2007) 4 SCC 599 : [2007) 4 SCR 279; Arasmeta Captive Power Company Private Limited and Anr. v. Lafarge India Private Limited (2013) 15 SCC 414 : [2013] 17 SCR 496; MR. Engineers and Contractors Pvt. Ltd. v. Som Datt Builders Ltd. (2009) 7 SCC 696 : [2009) 10 SCR 373 - referred to.

D

E

F

Per Kurian, J. (Supplementing):

¶63

1.1 The submission that the Memorandum of Understanding (MoU) has subsumed all the separate agreements and therefore and thereafter there can only be one agreement and, if so, only one Arbitral Tribunal for all the disputes emanating from the five different agreements and the Corporate Guarantee, is misconceived. The whole purpose of the MoU is evident from its text. It is clear that there is no novation by substitution of all the five agreements nor is there a merger of all into one. The

G

H

292

SUPREME COURT REPORTS

¶68

[2017] 10 S.C.R.

¶69

A reference to Original Package No. 4 Tender Document is only for better clarity on technical and execution related matters. 7. The said finding is wholly in line with Section 7(5) of the 1996 Act, which deals with incorporation by reference. The words "the reference is such as to make that arbitration clause part of the

¶70

B^{contract"areof relevance. Essentially, the parties must have} the intention to incorporate the arbitration clause. The detailed analysis of Section 7(5) in M.R. Engineers case fortifies the conclusion that the MoU does not incorporate an arbitration clause. [Para 5, 6, 7]

¶71

1.2 The submission that it is expedient that a single Arbitral

¶72

C Tribunal is constituted, also cannot be appreciated. The parties are free to agree to anything for their convenience but once such terms are reduced to an agreement, they can resile from them only in accordance with law. [Para 9J

¶73

1.3 The scope of the power under Section 11 (6) of the 1996

¶74

D Act was considerably wide in view of the decisions in SBP and Co. and Boghara Poly/ab cases. This position continued till the amendment brought about in 2015. After the amendment, all that the Courts need to see is whether an arbitration agreement exists - nothing more, nothing less. The legislative policy and purpose

¶75

E is essentially to minimize the Court's intervention at the stage of appointing the arbitrator and this intention as incorporated in s. 11 (6A) ought to be respected. [Para 13]

¶76

1.4 Jn the instant case, there are six arbitrable agreements

¶77

(five agreements for works and one Corporate Guarantee) and

¶78

F each agreement contains a provision for arbitration. Hence, there has to be an arbitral tribunal for the disputes pertaining to each agreement. While the arbitrators can be the same, there has to be six tribunals - two for international commercial arbitration involving the Spanish Company-petitioner and four for the domestic. [Para 14]

¶79

G M.R. Engineers and Contractors Pvt. Ltd v. Som Datt Builders Ltd. (2009) 7 SCC 696 : [2009) 10 SCR 373; S.B.P & Co v. Patel Engineering Ltd and Anr. (2005) 8 SCC 618 : [20051 4 Suppl. SCR 688; Konkan Railway Corpn. Ltd. and Ors. v. Mehul Construction Co. (2000)

¶80

H 7 SCC 201 : [2000) 2 Suppl. SCR 563; Konkan Railway

¶81

MIS. DURO FELGUERA, S. A. v. MIS. GANGAVARAM PORT LIMITED

¶82

293

¶83

Corpn. Ltd. & Anr. v. Rani Construction Pvt. Ltd (2002) 2 SCC 388 : [2009) 10 SCR 373; National Insurance Company Limited v. Boghara Polyfab Private Limited (2009) 1 SCC 267 : (2008) 13 SCR 638 - referred to.

¶84

A

¶85

Case Law Reference

¶86

In the .Judgment of Banumathi2	J :	B
[2000)2 Suppl. SCR563	refer.redto Para14
[2009)10SCR373	referredto Para14
[2005]4 Suppl. SCR688	referred to Para15
[2008)13 SCR638	referredto Para16	c
[2007)4 SCR279	referredto Para16
(2013]17SCR 496	referredto Para16
[2012]13SCR402	distinguished Para40	D
[2009)10SCR373	referredto Para34
In the Judgment of Kurian2J.:
[2009]10SCR373	referredto Para7	E
[2005)4 Suppl. SCR688	referredto Para11
[2000]2 Suppl. SCR563	referredto Para11
[2009)10SCR373	referred to Para11
[2008]13SCR638 CIVIL ORIGINAL JURISDI 30 of2016	referredto Para12 CTION : Arbitration Petition No.	F

¶87

In the .Judgment of Banumathi2 J :

¶88

WITH Arbitration Petition No. 31 of2016 G T. C. (C) No.25 of2017 T. C. (C) No.26 of2017 T. C. (C) No.27 of2017 T. C. (C) No.28 of2017 H

¶89

294

¶90

SUPREME COURT REPORTS

¶91

[2017] 10 S.C.R.

¶92

A Mukul Rohatgi, Raju Ramachandran. Sunil Gupta, Dr. Abhishek Manu Singhvi, Sr. Advs., Ms. Anitha Shenoy, Ms. Rashmi Nandakumar, Ms. Srishti Agnihotri, Ms.Hamsini Shankar, lshwar Mohanty. Tarun Dua, Ms.Geetanjali Sethi, Faisal Sherwani,A. Paul, Ms.Sumati Sharma. Advs. for the appearing parties.

¶93

B The Judgment of the Court was delivered by

¶94

BANUMATHI, J. Arbitration Petition No.30 of 2016 has been filed by Mis Duro Felguera, S.A. under Section I l(6)(a) read with Sectiion I! ( l 2)(a) of the Arbitration and Conciliation Act, l 996 (for short, 'the Act·) to appoint the nominee arbitrator on behalf of the respondent c (second arbitrator) in terms of sub-clause 20.6 of the Special Conditions of the Contract with respect to the arbitration arising under the Contract dated l 0.05.2012. T.C. No.25 of 2017, T.C. No.26of2017, T.C. No.27 of2017 and T.C. No.28 of 2017 have been filed by M/s. Felguera Gruas India Private Limited (hereinafter referred to as 'the FGI') for appointment of Domestic Arbitral Tribunal for resolving the dispute D pertaining to the contract awarded to FGI. Arbitration Petition No.31 of 2016 has been filed by M/s. Gangavaram Port Limited (hereinafter referred to as 'the GPL') to appoint an arbitrator under the Memorandum of Understanding (MoU) dated 11.08.2012 and to constitute a single Arbitral Tribunal by a composite reference for adjudication of all the E disputes between the parties in connection with the "Works" covered under all the five Package Contracts and the Corporate Guarantee dated 17.03.2012 executed by Duro Felguera.

¶95

As the pa1ties and issues in both the arbitration petitions and the transfeJTed cases are one and the same, both arbitration petitions and F the transferred cases shall stand disposed of by this common order. For convenience, parties arc referred to as per their array in Arbitration Petition No.30of2016.

¶96

BriefFacts: The Respondent-Gangavaram Port Limited (GPL) developed a green-field, ultra-modern, all-weather sea-port near G Gangavaram Village in Visakhapatnam District in the State of Andhra Pradesh. This sea-port commenced operations in the year 2009. The Respondent intended to expand its facilities in the Pm1 with respect to Bulk Material Handling Systems. This included Engineering, Design, Procurement of Materials, Manufacturing, Supply, Erection, Testing and Commissioning of Bulk Material Handling Systems, as well as all other

¶97

H

¶98

295

¶99

MIS. DURO FELGUERA, S. A. v. M/S. GANGAVARAM PORT LIMITED [BANUMATHI, J.]

¶100

associated works and integration of the same with the existing coal A handling systems etc. For this purpose, on 08.08.2011, Gangavaram Port Limited invited a tender/bid. In response to the aforementioned tender dated 08.08.2011, the Spanish Company-Duro Felguera Plantas Industrials S.A. (since merged with the petitioner) along with its Indian 'subsidiary-Mis. Felguera Gruas India Private Limited (FGI) submitted a B Single Bid/Tender-Original Package No.4 Tender Document on 15.11.2011. This included the Commercial Bid and the Technical Bid. After post-bid negotiations, the petitioner Duro Felguera and its subsidiary (FGI) were considered by GPL and Duro Felguera and FGI were selected as "the Contractors" for the work.

¶101

A

¶102

c

¶103

After discussion between the parties, Original Package No. 4 TD was divided into five different and separate Packages, namely, New Package No. 4-F.O.B. Supply of Bulk Material Handling Equipments (awarded to foreign company-Mis Duro Felguera), Package No. 6- design, manufacture, supply, installation, erection, testing, commissioning of Bulk Material Handling Equipments and all other activities related therewith; Package No. 7-Civil Works and all other activities related therewith; Package No. 8-International Transportation of Bulk Material Handling Equipments and parts through sea including insurance and all related activities; Package No. 9-Installation, Testing and Commissioning of Ship Unloaders and all other activities related therewith (Packages No.6 to 9 awarded to Indian subsidiary-FGI). Separate Letters of Award (dated 17.03.2012) for five different Packages were issued to Mis Duro Felguera, S.A. and the Indian Subsidiary-FGI forthe above said work respectively.

¶104

D

¶105

E

¶106

Five different contracts were entered into on 10.05.2012 for F five split-up Packages with different works viz. namely New Package No. 4 with foreign company-Mis Duro Felguera and Packages No. 6, 7, 8 and 9 with FGI. Each of the Packages has special conditions of contract as weU as general conditions of contract. Each one of the Contract/ Agreement for works under split-up Packages contains an arbitration clause namely sub-clause 20.6. Duro Felguera had also entered into a G Corporate Guarantee dated 17.03.2012 guaranteeing due performance of all the works awarded to Duro Felguera and FGI. The said Corporate Guarantee had its own arbitration clause namely clause (8).

¶107

Duro Felguera and FGihave executed a tripartite Memorandum of Understanding (MoU) with Mis Gangavaram Port Limited (GPL) on

¶108

H

¶109

296

¶110

SUPREME COURT REPORTS

¶111

[2017] 10 S.C.R.

¶112

A 11.08.2012. In the said MoU. Duro Felguera and FGI have agreed to carry out the works as per the priority of documents listed therein. Case ofGPL is that the MoU dated 11.08.2012 being the latest covers all the five contracts namely New Package No. 4 awarded to M/s Duro Felguera and Packages No. 6 to 9 awarded to FGI. According to GPL, since MoU refers to original Package No. 4 Tender Document (TD)

¶113

B which contains arbitration clause, the Original Package No. 4 TD with its arbitration clause shall be deemed to have been incorporated in the MoU.

¶114

Case of Mis. Gangavaram Port Limited is that the petitioner-

¶115

M/s Duro Felguera, S.A. and its Indian Subsidiary-FGI failed to perform

¶116

c their obligations, including their obligation to attend and rectify faulty works and complete the pending works etc. Further grievance ofGPL is that though the works were scheduled to be completed at the latest by 16.03.2014, the petitioner-Mis Duro Fclgucra, S.A. and its Indian Subsidiary (FGI) caused inordinate delay in execution of the work and,

¶117

D therefore, GPL was constrained to invoke the Bank Guarantee on 07.01.2016 given by petitioner-Mis Duro Felguera. GPL had also issued Notices of Termination dated 31.01.2016 to the Foreign Company-Mis Duro Felguera and its Indian Subsidiary(FGI). Mis Duro Felguera, S.A. and its Indian Subsidiary (FGI) issued notice of dissatisfaction on 04.02.2016 and 07.02.2016 to GPL. Subsequently Mis. Duro Felguera

¶118

E issued an arbitration notice dated 05.04.2016 for New Package No. 4 Contract and FGI issued four arbitration notices dated 07.04.2016 for Packages No. 6 to 9 Contracts. Both Mis. Duro F elguera and FG I have separately nominated Mr. Justice D.R. Deshmukh (Former Judge, Chhattisgarh High Court) as their nominee arbitrator for each of the five

¶119

F contracts.

¶120

GPL issued a comprehensive arbitration notice on l 3.04.2016 appointing Mr. Justice M.N. Rao (Former Chief Justice, Himachal Pradesh High Court) as its nominee arbitrator under sub-clause 20.6 of the conditions of contract which form part of the "Original Package No. G 4 Tender Document". Contention ofGPL is that "Original Package No. 4 (TD) and the Corporate Guarantee by Mis. Duro Felguera" and the MoU dated 11.08.2012 cover all the five contracts, namely, New Package No. 4, Package No. 6, Package No. 7, Package No. 8 and Package No. 9 as well as the Corporate Guarantee. Further case ofGPL is that five individual arbitration notices issued by Mis. Duro Felguera and FGI are

¶121

H

¶122

297

¶123

MIS. DURO FELGUERA, S. A. v. MIS. GANGAVARAM PORT LIMITED [BANUMATHI, J.]

¶124

untenable and since Duro Felguera-the foreign company has guaranteed the due performance of the works covered under all the five packages and there has to be only one single Arbitral Tribunal for resolving the disputes of"International Commercial Arbitration" arising between the parties.

¶125

Mr. Mukul Rohtagi and Mr. RajuRamachandran, learned Senior Counsel for Mis Gangavaram Port Limited (GPL) submitted that the split up of the "Works" into five separate contracts was made only on the basis of the requests made by the Duro Felguera for convenience of the contractors. It was contended that all the works are inter-connected and inter-linked and if there arc separate arbitrations for each of the packages, and separate arbitration for New Package No. 4 and the Corporate Guaritntee take place, then in each arbitration, the respondent party will blame the lapse on the part of GPL in another Package and thereby attempt to escape liability. It was urged that the appointment of a single arbitral tribunal, under the MoU and the Corporate Guarantee will avoid conflicting awards between the pa1iics, huge wastage of time, resources and expenses; and would be consistent with law and public policy. The learned Senior Counsel further submitted that MoU was executed by Duro Felguera and FGI on 11.08.2012 and the contents of MoU including the priority of the documents referred therein prevail over the contents of the Letters of Award and the Contracts. It was, therefore, submitted that the arbitration clause covered under sub-clause 20. 6 of the conditions of contract, which forms part of the "Original Package No. 4 Tender Document" which is incorporated in the MoU shall prevail over the arbitration clause covered under sub-clause 20.6 of the contract for five packages. It was further submitted that having regard to the nature of disputes which extend over each of the Packages and collectively covered the Corporate Guarantee executed by Duro Fclguera under MoU, it would be just and proper to· make a 'composite reference' and have a single arbitral tribunal of "international commercial arbitration' for settling the dispute arising between the parties and the same would be consistent with the intention of the parties and public policy. It was urged that the contract for the "Works" has always been envisaged by the parties as one composite contract even though the contracts were split into various Packages and there cannot be multiple arbitral tribunals for adjudication of disputes between the _parties as it would lead only to complications in settling the disputes and execution of the awards.

A

B

c

D

E

F

G

H

298

SUPREME COURT REPORTS

¶136

[2017] I 0 S.C.R.

¶137

A JO. Mr. Sunil Gupta learned Senior Counsel appearing for Duro Felguera-Spanish Company submitted that by conscious agreement of the parties, the Original Package No.4 Tender Document was superseded by five new Contracts with different works namely New Package No. 4, Packages No.6, 7, 8 and 9, each of which have special co~ditions as well as general conditions of contract. It was further submitted that the B Corporate Guarantee dated 17.03.2012 executed by Duro Felgucra g1,1aranteeing due performance of the works awarded to Duro Felguera and FGI has its own separate and distinct arbitration clause and the same has no connection with the arbitration clauses (sub-clause 20.6) of the five different contracts for New Package No. 4 and Packages No. c 6, 7, 8 and 9. The learned Senior Counsel further submitted that the MoU dated 11.08.2012 which enlists priority of the documents to be considered is only to have clarity in carrying out the works and the MoU cannot override the terms of the contracts for five different packages including the arbitration clauses contained therein. It was submitted that D the five new split-up Packages followed by five different Letters of Award and five difforent contracts were substantially different, independent and separate in their content and subject matter and there cannot be a 'composite reference' for efficacious settlement of disputes, it would be just and proper to have multiple arbitral tribunals and may be by the same arbitrators. The learned Senior Counsel submitted that so E far as New Package l'-io.4 and the issues J'ertaining to the Corporate Guarantee executed on 17.03.2012 by Duro Felguera-the foreign Company, the arbitral tribunal has to be for International Commercial Arbitration.

¶138

II. Reiterating the above submissions, Mr. Singhvi, the learned F Senior Counsel appearing for Indian subsidiary-FGI contended that by conscious decision and agreement of the parties, Original Package No. 4 (TD) was superseded and five new TDs with different works namely TD for New Package No. 4 and Packages No. 6, 7, 8 and 9 were brought into existence and there were separate Letters of Award and five separate contracts for each one of those split-up packages. It was G · submitted that each of the contracts contain special conditions as well as general conditions of contract apart from the arbitration clause, (subclause 20.6), which is relevant for governing the contractual and arbitral relations between the parties and in case of dispute arising between the parties under any of the respective contracts or the Corporate Guarantee, H the aggrieved party would have to invoke the respective arbitration clauses

¶139

'

¶140

MIS. DURO FELGUERA, S. A. v. M/S. GANGAVARAM PORT LIMITED [BANUMATHI, J.]

¶141

299

¶142

in the respective contracts in question and cannot invoke the MoU dated 11.08.2012. It was further submitted that the Corporate Guarantee dated 17 .03 .2012 was executed by Duro Felguera under which it had gtiaranteed the due performance of all the works awarded to Duro Felguera and FGI and FGI is not a party under the said Corporate Guarantee. It was further submitted that the MoU dated 11.08.2012 came into existence long after the Contracts and it does not contain any arbitration clause and MoU does not intend to alter the nature of the rights, responsibilities and obligations of the pat1ies arising from the respective contracts and, therefore, for settling the disputes arising under the Packages No. 6, 7, 8 and 9 awarded to FGI, there have to be four domestic arbitral tribunals and there cannot be a 'composite reference' by invoking MoU.

A

B

C

Considering the facts and circumstances and rival contentions of the pat1ies, the following points arise for determination:

¶147

(1) Whether Gangavaram Port Limited (GPL) is right in contending that Memorandum of Understanding (MoU) D dated 11.08.2012 and Original Package No. 4 Tender Document and Corporate Guarantee dated I 7 .03.2012 executed by Duro Felguera covers all the five split-up Packages awarded to Duro Felguera and FGI and whether there has to be a composite reference/single arbitral tribunal E for "International ·Commercial Arbitration" covering all the five different Packages and also the Corporate

¶148

-. Guarantee executed by Duro Fclguera?

¶149

(2) Whether there have to be 'mult1]J/e arbitral tribunals' for each of the five different Packages of Work awarded to F the foreign company-Duro Felguera and Indian SubsidiaryFGI (one International Commercial Arbitral Tribunal plus four Domestic Arbitral Tribunals) and another one arbitral tribunal for 'international commercial arbitration' under Corporate Guarantee (17 .03.2012) executed by the foreign G

¶150

company-Duro Felguera?

¶151

G

¶152

The Arbitration and Conciliation (Amendment) Act, 2015 (w.e.f. 23.10.2015) has brought in substantial changes in the provisions of the Arbitration and Conciliation Act, 1996. After the Amendment Act 3 of2016, as per the amended provision of sub-section (6A) of Section 11,

¶153

H

¶154

300

¶155

SUPREME COURT REPORTS

¶156

[2017] IO S.C.R.

¶157

A the power of the court is confined only to examine the existence of the arbitration agreement. It further clarifies that the decision of appointment of an arbitrator will be made by the Supreme Court or the High Court (instead of Chief Justice) and under Section 11 (7), no appeal shall lie against such an appointment.

¶158

B Position prior to Amendment Act 3 of 2016

¶159

Under Section 11 (6) of the Arbitration and Conciliation Act, 1996, as it stood prior to Amendment Act 3 of 2016, on an application made by any of the parties, the Chief Justice of the High Court appoints an arbitrator for adjudication. Initially, the line of decisions ruled that the c appointment of arbitrator is an administrative order passed by the Chief Justice. In Konkan Railway Corporation Limited and Others v. Mehul Construction Company, (2000) 7 SCC 20 l, it was held that the powers of the ChiefJustice under Section 11(6) of the Arbitration and Conciliation Act, 1996 are of administrative nature and that the Chief Justice or his designate does not act as a judicial authority while appointing an arbitrator. D The same view was reiterated in the subsequent judgment of this Court in Konkan Railway Corporation Limited and Another v. Rani Construction Private Limited, (2002) 2 SCC 388.

¶160

However, in the year 2005, a Constitution Bench of Seven Judges in SBP and Co. v. Patel Engineering Limited and Another, E (2005) 8 sec 618, made a departure from the previous judgments and held that the order passed by the Chief Justice is not administrative but judicial in nature and hence the same is subject to appeal under Article 136 of the Constitution ofindia. The Court further held that in deciding the appointment of an arbitrator, the Chit:f Justice could first by way of F a preliminary decision decide the court's own jurisdiction of that matter to entertain the arbitration petition, the existence of a valid arbitration agreement, the subsistence of a "live claim i.e. the claim that is not barred by limitation".

¶161

The judgment in SBP and Co. (supra) was further clarified G in National /11s11rance Company Limited v. Boghara Poly/ab Private Limited, (2009) l SCC 267, wherein this Court held that while appointing an arbitrator, the following could be considered:-

¶162

"22. Where the intervention of the court is sought for appointment of an Arbitral Tribunal under Section 11, the duty of the Chief Justice or his designate is defined in H

¶163

MIS. DURO FELGUERA, S. A. v. MIS. GANGAVARAM PORT 301 LJMITED [BANUMATHI, J.]

¶164

SBP & Co. (2005) 8 SCC 618. This Court identified and A segregated the preliminary issues that may arise for consideration in an application under Section 11 of the Act into three categories, that is, (i) issues which the Chief Justice or his designate is bound to decide; (ii) issues which he can also decide, that is, issued which he may B choose to decide; and (iii) issues which should be left to the Arbitral Tribunal to decide."

¶165

The judgments in Shree Ra111 Mills Ltd. v. Utility Premises (P) Ltd, (2007) 4 SCC 599 and Aras111eta Captive Power Co111pany Private Limited and Another v. Lafarge India Private Limited, (2013) 15 sec 414, are on the same line pertaining to the issues which have to be dealt with by the Chief Justice or his designate.

¶166

c

¶167

Changes brought about by the Arbitration and Conciliation (Amendment) Act, 2015 (Amendment Act 3 of 2016)

¶168

The language in Section II ( 6) of the Act "the Chief.Justice or any person or institution designated by him" has been substituted by "Supreme Court or as the case may be the High Court or any persoi1 or institution designated by such Court". Now, as per subsection ( 6A) of Section 11, the power of the Court has now been restricted only to see whether there exists an arbitration agreement. The amended provision in sub-section (7) ofScction 11 provides that the order passed under Section I I (6) shall not be appealable and thus finality is attached to the order passed under this Section. The amended Section 11 reads as under:-

¶169

D

¶170

E

¶171

"11. Appointment of arbitrators.- (I) A person of any nationality may be an arbitrator, unless otherwise agreed by the F paiiies.

¶172

(2) Subject to sub-section (6), the parties are free to agree on a procedure for appointing the arbitrator or arbitrators.

¶173

(3) Failing any agreement referred to in sub-section (2), in an arbitration with three arbitrators, each party shall appoint one arbitrator, and the two appointed arbitrators shall appoint the third arbitrator who shall act as the presiding arbitrator.

¶174

G

¶175

( 4) If the appointment procedure in sub-section (3) applies and-

¶176

H

¶177

302

¶178

SUPREME COURT REPORTS

¶179

(2017] 10 S.C.R.

¶180

A

¶181

(a) a party fails to appoint an arbitrator within thirty days from the receipt of a request to do so from the other party; or

¶182

(b) the two appointed arbitrators fail to agree on the third arbitrator within thirty days from the date of their appointment,

B

c

D

the appointment shall be made, upon request of a party, by '[the Supreme Court or, as the case may be, the High Court or any person or institution designated by suclt Court].

¶187

(5) Failing any agreement referred to in sub-section (2), in an arbitration with a sole arbitrator. if the parties fail to agree on the arbitrator within thirty days from receipt of a request by one party from the other party to so agree the appointment shall be made, upon request of a party, by *[tlte Supreme Court or, as the cme may be, the High Court or any person or institution designated by such Court}.

¶188

(6) Where. under an appointment procedure agreed upon by the parties,-

¶189

( a) a party fails to act as required under the procedure; or

¶190

E

¶191

(b) the parties, or the two appointed arbitrators, fail to reach an agreement expected of them under that procedure; or

¶192

( c) a person, including an institution, fails to perform any function entrusted to him or it under that procedure,

F

G

H

a party may request *[the Supreme Court or, as tlte case may be, the High Court or any person or institution designated by such Court] to take the necessary measure, unless the agreement on the appointment procedme provides other means for securing the appointment.

¶197

*[(6A) The Supreme court or, as the case may be, the High Court, while considering any application under subsection (4) or sub-section (5) or sub-section (6), shall, notwithstanding any judgment, decree or order of any Court, confine to the examination of the existence of an arbitration agreement.]

¶198

*[(6B) The designation of any person or institution by the Supreme Court or, as the case may be, the High Court, for

¶199

M/S. DURO FELGUERA, S. A. v. M/S. GANGAVARAM PORT 303 LIMITED [BANUMATHI, J.]

¶200

the purposes of this section .~/tall not be regarded as a A delegation of judicial power by the Supreme Court or tlte High Court.}

¶201

(7) A decision on a matter entrusted by sub-section ( 4) or sub-section (5) or sub-section (6) to *[the Supreme Court or, as the case may be, tlte High Court or the person or i11Stitution desig11ated by such Court is final and no appeal including Letters Patent Appeal shall lie ag1dnst such decision].

¶202

B

¶203

*[(8) The Supreme Court or, as the case may be, the High Court or the perso11 or i11stitution designated by such Court, before appointing an arbitrator, shall seek a disclosure in c writing from the prospective arbitrator i11 terms ofsub-sectio11 _ - (1) of sectio11 12, and have due regard to-

¶204

(a) any qualifications required of the arbitrator by the agreeme11t of the parties; a11d

¶205

(b) the co11te11ts of the disclosure and other co11Siderations D as are likely to secure the appointment of a11 independe11t and impartial arbitrator.]

¶206

(9) In the case of appointment of sole or thii:_d arbitrator in an international commercial arbitration, *[the Supreme Court or the person or institution designated by that Court} may appoint - E an arbitrator of a nationality other than the nationalities of the parties where the parties belong to different nationalities.

¶207

*[(10) The Supreme Court or, as the case may be, the High Court, may make such scheme as the said Court may deem appropriate for dealing with matters entrusted by subsection (4) or sub-section (5) or sub-section (6), to it.]

¶208

( 11) Where more than one request has been made under subsection (4) or sub.section (5) or sub-section (6) to *[different High Courts or their designates, the High Court or its designate to whom the request has been first made} under the relevant sub-section shall alone be competent to decide on the request.

¶209

F

¶210

G

¶211

*[(12)(a) Where the matters referred to in sub-sections (4), (5), (6), (7), (8) and sub-section (10) arise in an international commercial arbitration, the refere11ce to the H

¶212

304

¶213

SUPREME COURT REPORTS

[2017] JO S.C.R.

A

B

c

"Supreme Court or, as the case may be, the High Court" in those sub-sections shall be construed as a reference to the "Supreme Court",· and

¶219

(b) where the matters referred to in sub-sections (4), (5), (6), (7), (8) a11d sub-section (10) arise in any other arbitration, the reference to "the Supreme Court or, as the l'a.se may be, the Higlt Court" in those sub-sections shall be construed as a reference to the "High Court" within whose local limits the principal Civil Court referred to in clause (e) of subsection(/) of section 2 is situate, a11d where the High Court itself is tlte Court referred to i11 tltat clause, to tltat Higlt Court.]

¶220

D

¶221

E

¶222

*{(13) An application made under tltis section for appoint111ent of an arbitrator or arbitrators sltal/ be disposed of by the Supreme Court or the High Court or lite person or institution designated by such Court, as the case may be, as expeditiously as possible and an endeavour shall be made to dispose of the matter within a period of sixty days fro111 the date of service of notice on the opposite party.

¶223

(14) For the purpose of determination of the fees of the arbitral tribu11al and the ma1111er of its payment to the arbitral tribunal, the High Court may frame such rules as may be necessary, after taking into consideration the rates specified in the Fourth Schedule.

¶224

Explanation.-For the removal of doubts, it is hereby clarified that this sub-section shall not apply to international F commercial arbitration and in arbitrations (other than international commercial arbitration) in case where parties ltave agreed for determination of fees as per tlte rules of an arbitra/ institution.]"

¶225

*Substituted by Act 3 of 2016 (w.e.f. 23.10.2015)

¶226

G

¶227

The effect of the Arbitration and Conciliation (Amendment) Act, 2015 in Section 11 of the Act has been succinctly elucidated in the text book "Law Relating to Arbitration and Co11ciliatio11 by Dr. P. C. Markanda", which reads as under:-

¶228

H

¶229

"The changes made by the Amending Act are as follows:

¶230

305

¶231

M/S. DURO FELGUERA, S. A. v. M/S. GANGAVARAM PORT LIMITED [BANUMATHI, J.]

¶232

The words 'Chief Justice or any person or institution designated by him' shall be substituted by the words 'the Supreme Court or, as the case may be, the High Court or any person or institution designated by such Court'. Thus, now it is not only the Chief Justice who can hear applications under Section 11, the power can be delegated to any judge as well.

¶233

As per sub-section (6-A), the power of the Court has now been restricted only to examination of the existence of an arbitration agreement. Earlier, the Chief Justice had been given the power to examine other aspects as well, i.e. limitation, whether the claims were referable for arbitration etc. in terms of the judgments of the Supreme Court in SBP and Co. v. Patel Engineering Ltd., (2005) 8 SCC 618; and National Insurance· Co. Ltd. V. Boghara Poly/ab Pvt. Ltd., (2009) 1 SCC 267. Now all preliminary issues have been left for the arbitral tribunal to decide in terms of Section 16 of the Act.

¶234

The Amending Act has categorically provided in sub-section (6-B) that designation ofany person or institution by the Supreme Court or High Court would not be construed as delegation of judicial power. The order passed by a designated person or institution would continue to be regarded as a judicial order.

¶235

It has been provided is sub-section (7) that the order passed under this section shall not appealable. This change means that finality is attached to the order passed under this section and it would not be subject to further examination by an appellate court.

¶236

Sub-section (8) has been amended to bring it in conformity with amended section 12 with regard to ensuring independence and impartiality of the arbitrator. Before appointing any arbitrator, a disclosure in writing has to be obtained in terms of section 12( l) of the Act. This is to ensure that the appointed arbitrator shall be independent and impaitial and also harmonizes the provisions of sections 11and12 of the Act.

¶237

The Amending Act has introduced sub-section (13) which provides that the disposal of the application under this section has to be expeditious and endeavour shall be made to dispose of the application within a period of 60 days from the date of service of notice on the opposite party. This sub-section would ensure

A

B

C

D

E

F

G.

H

306

SUPREME COURT REPORTS

¶248

[2017] l 0 S.C.R.

¶249

A

¶250

speedy disposal of applications under this section and all contentious issues have been left to be decided by the arbitral tribunal.

¶251

For determining the fee structure of the arbitral tribunal, it has been recommended that the High Courts may frame the B necessary rules and for that purpose, a model fee structure has been provided in the Fourth Schedule of the Amending Act. However, this sub-section would not be applicable for the fee structure in case of international commercial arbitrations and domestic arbitrations where the parties have agreed for determination of fee as per rules of an arbitral institution. This c sub-section has been inserted to ensure a reasonable fee structure since the cost of arbitration has increased manifold due to high charges being levied on the parties by the arbitral tribunal and other incidental expenses.

¶252

B

¶253

[Reference: Law Relating to Arbitration and Conciliation by Dr. P.C. Markanda; Lexis Nexis, Ninth Edition, Page 460)

¶254

D

¶255

There is no dispute between the parties that the issue at hand is governed by the amended provision of sub-section (6A) of Section 11. Even though Letters of Award are dated 17.03.2012 and five separate E contracts were entered into between the parties on 10.05.2012, the dispute arose between the parties in 2016 as pointed out earlier, Gangavaram Port Limited invoked the Bank Guarantee on 07.01.2016 and Mis. Dura Felguera and its Indian Subsidiary-FGI issued notice of dissatisfaction on 04.02.2016 and 07.02.2016 respectively to Gangavaram F Port Limited. Mis. Dura Felguera issued arbitration notice on 05.04.2016 for contract relating to Package No. 4 and FGI issued four arbitration notices dated 07.04.2016 for contracts relating to Packages No. 6 to 9. Gangavaram Port Limited also issued an arbitration notice on 13.04.2016. Since the dispute between the parties arose in 2016, the amended provision of sub-section (6A) of Section 11 shall govern the issue, as per G which the power of the Court is confined only to examine the existence of the arbitration agreement.

¶256

Whether there has to be a Single Arbitral Tribunal for 'International Commercial Arbitration' or 'Multiple Arhitral Tribunals'?

¶257

H

¶258

M/S. DURO FELGUERA, S. A. v. MIS. GANGAVA'RAM PORT LIMITED [BANUMATHI, J.]

¶259

307

¶260

Original Package No.4 Tender Document for Gangavaram A Port Limited Expansion-2011 consisted of "Bulk Material Handling Systems including Engineering, Design, Procurement of Materials, Manufacturing, Supply erection, testing and coriunissioning of bulk material handling systems including all other 0:5sociated works and integration of the same with the existing coal handling systems B (Package 4- "Works''). By mutual consent and agreement of the parties, Original Package No.4 TD was split into five different Packages-New Package No. 4 [awarded to Duro Felguera (Spanish Company)] and Packages No. 6, 7, ~and 9 awarded to its Indian subsidiary-FGI. Letters of Award dated 17.03.2012 was awarded to Duro Felguera and FGI for various Packages. Pursuant to Letters of Award, parties have entered C into contract agreement on 10.05.2012. These split-up contracts have Volume I-Conditions of Contract; Volume II-Employer's Requirement,. Scope ofWork, Specifications and Drawings; and Volume Ill-Schedule of Prices. Five different Packages, the Letters of Award and the contract awarded to Duro Fclguera and FGI and the Scope of Work and the D value thereof, read as under:

A

C

D

Package& Parties (ll	L.0.A. (2)	DateofContract& theScopeofWork 13)	Value/Price (4)
No.4 GPL-DF (Spain)	17.o3.2012	10.5.12 f.O.B. SUPPLY Of BULK MATERIAL HANDLING EQUIPMENTS	USO26,666,932
No.6 GPL-FGI (India)	17.03.2012	10.5.12 Design, manufacture, supply, installation, erection, testing, commissioning of Bulk Material Handling Equipmentsand all other activities relatedtherewith	Rs.208,66 ,53 ,65 7
No.7 GPL-FGI (India)	17.03.2012	10.5 .12 Civilworksandall other activities relatedtherewith	Rs.59,14,65,706
No.8 GPL-FGI (India)	17.03.2012	10.5.12 International Transportation of BulkMaterial	Rs.9,94,38,635

E

F

G

H

308

SUPREME COURT REPORTS

[2017] IO S.C.R.

B

D

A

c

		Handling Equipmentsand Partsthroughsea including insuranceandall relatedactivities
No.9 GPL-FGI (India)	17.03.2012	10.5.12 Installations, testing, commissionof shipUnloaders andother activities. 25.7.14 Variationof Contract	Rs.29,52,85,558 Someworks deleted&price reducedto Rs.12,63,03,095
THEC	ORPORATE	~~GUARANTEECO ~~	NTRACf
GPL-DF (Spain)	17.03.2012 Corporate Guarantee	..... ....	Arbitration Oanse-Cl.8

¶277

On behalf of GPL, it was repeatedly urged that the works are intrinsically connected, inseparable, integrated, interlinked and that they are one composite contract and that they were split up only on the request and representations given by Duro Felguera and FGI. As discussed E earlier, as per amended provision Section 11 (6A), the power of the Supreme Court or the High Court is only to examine the existence of an arbitration agreement. From the record, all that we could sec arc five separate Letters of Award; five separate Contracts; separate subject matters; separate and distinct work; each containing separate arbitration F clause signed by the respective parties to the contract.

¶278

All the above five contracts awarded to Duro Fclguera and FGI have independent arbitration clauses. Mr. Sunil Gupta and Mr. A.M. Singh vi, learned Senior Counsel have taken us through the contract agreements in New Package No. 4 awarded to Mis Duro Felgucra and G Package No.6 (for sample) awarded to FGI and submitted that all the five different contracts have independent arbitration clauses (in subclause 20.6). In the contract New Package No.4 there is a header "Supp~v of Bulk Material Handling Equipments and Parts on FOB Basis". Likewise, contract agreement for Package No.6 contains the header "Design, manufacture, supply, installation, erection, testing

¶279

H

¶280

MIS. DURO FELGUERA, S. A. v. MIS. GANGAVARAM PORT LIMITED [BANUMATHI, J.)

¶281

309

¶282

commissioning of Bulk Material Handling Equipments and all other A activities related therewJth ". Various clauses in the Original TD Package No.4 were suitably modified and incorporated in the split-up contract agreements. Sub-clause 20.6 dealing with arbitration in the original Package No.4 TD has been reproduced in New Package No.4 and other Packages No. 6 to 9. The contract for New Package No. 4 B which was entered into between Mis. Duro Fclgucra and GPL, also contains an arbitration clause, which reads as under:

¶283

"Sub-Clause 20.6 - Arbitration

¶284

Any dispute in respect of which amicable settlement has not been reached within the period stated in Sub-Clause 20.5, shall c be finally and conclusively settled by Arbitration under the Arbitration and Conciliation Act, 1996 by appointing two arbitrators one by each party and a presiding arbitrator to be appointed by the said arbitrators. Any such arbitration proceeding shall be within the exclusive jurisdiction of court of law at Hyderabad, India. The place of Arbitration shall be Hyderabad and the D Language of Arbitration shall be English. The Contractor shall continue to attend to discharge all his obligations under the Contract during pendency of the Arbitration proceedings."

¶285

Likewise, the four different contract Packages No. 6, 7, 8 and 9 which were awarded to FGI for different works also contain an arbitration clause. Sub-clause 20.6 of Package No.6-Design, manufacture, supply, installation, erection testing, commissioning of Bulk Material Handling Equipments etc., reads as under:-

¶286

E

¶287

"Sub-Clause 20.6 - Arbitration

¶288

F

¶289

Any dispute in respect of which amicable settlement has not been reached within the period stated in Sub-Clause 20.5, shall be finally and conclusively settled by Arbitration under the Arbitration and Conciliation Act, 1996 by appointing two mbitrators one by each party and a presiding arbitrator to be appointed by the said arbitrators. Any such arbitration proceeding shall be within the exclusive jurisdiction of court of law at Hyderabad, India. The place of Arbitration shall be Hyderabad and the Language of Arbitration shall be English. The Contractor shall continue to attend to discharge all his obligations under the Contract during pendency of the Arbitration proceedings."

G

H

310

SUPREME COURT REPORTS

¶294

[2017] IO S.C.R.

¶295

A Like Package No. 6. Contract/Agreement pertaining to other packages awarded to FGI, namely, Packages No.7, 8 and 9 also contain similar arbitration clause in sub-clause 20.6. The Original Package No. 4 TD split into five different Packages, each having different works prima facie indicates the intention of the parties to split-up original Package No. 4 TD into five different packages, as was discussed above. 8

¶296

In the contract agreement, the parties have agreed that the documents mentioned in clause (2) of the agreement will have priority. Clause (2) of the agreement in New Package No. 4 awarded to Duro Felguera, reads as under:-

¶297

C "2.The following documents shall form and be read and construed as part of this Agreement and shall have the priority one over the other in the following sequence:

¶298

(a) this Agreement;

¶299

(b) the Letter of Award;

¶300

D ( c) Special Conditions of Contract (Conditions of Particular Applications)

¶301

(d) General Conditions of Contract;

¶302

( e) the Employer's Requirements, Scope ofWork, Specifications

¶303

E and Drawings;

¶304

(t) the Schedule of Prices;

¶305

(g) the Tender to the extent annexed herewith."

¶306

Similar clauses as to the priority of the documents was incorporated in F all other contract agreements-Packages No. 6, 7, 8 and 9 awarded to Indian subsidiary FGI. In the sequence of documents of clause (2) of the contract agreement quoted above, the Tender Document is mentioned in the sequence only as (g) and all other documents or the other documents like Letters of Award, Special conditions of contract etc. have priority over the same. While so, the terms contained in Original Package No. G 4 TD including the arbitration clause cannot have priority over the Special Conditions of contract of the split-up contracts. When the Original Package No. 4 TD has been split-up into five different Packages, GPL is not right in contending that inspite of split-up of the work, the Original Package No.4 TD collectively covered all the five Packages. After the H Original Package No. 4 was split into five different contracts, the parties

¶307

MIS. DURO FELGUERA, S. A. v. MIS. GANGAVARAM PORT 311 LIMITED [BANUMATHI, J.]

¶308

cannot go back to the Original Package No.4 nor can they merge them into one. We do not find merit in the submissions ofGPL that sub-clause 20.6 of the Original Package No. 4 TD will still collectively cover all the five Packages to justify constitution of single Arbitral Tribunal.

¶309

A

¶310

The foreign company-Duro Felguera had executed a Corporate Guarantee dated 17.03.2012 guaranteeing the due performance of all the works awarded to Duro Fclguera andFGI. The Corporate Guarantee itself has its own separate and distinct arbitration clause. The arbitration clause of the Corporate Guarantee i.e. clause (8) reads as under:

¶311

B

¶312

"8. This Corporate Guarantee shall be governed by the Indian Laws. In case of any disputes, the Parties shall c endeavor to settle the same amicably. In case of failure to settle the disputes amicably, the same shall be finally settled under the Arbitration and Conciliation Act 1996 of India by appointing two Arbitrators, one by each party and a Presiding Arbitrator to be appointed by the said Arbitrators. The award of the Arbitrators shall be final D and binding on the Corpoi:ate Company and the Employer. Any such Arbitration proceeding shall be at Hyderabad and within the Jurisdiction of the Court of Law at Hyderabad, Andhra Pradesh, India.The Arbitration shall be conducted in English language." E

¶313

D

¶314

In the Corporate Guarantee, Duro Felguera has undertaken to ensure performance of all the works both by Duro Felguera and also the contracts pertaining to Packages No. 6 to 9 awarded to FGI. Duro . F elguera has also undertaken that in the event of any delay in completion of the works as per the time stipulated for completion of the contracts, Duro Felguera had undertaken to compensate for the delay, damages to GPL which will be based on the overall contract price collectively of all the contracts. The relevant clauses read as under:-

¶315

F

¶316

"1. The Corporate Company hereby guarantees and covenants with the employer that FGI will perform all its obligations and duties as per package 6 to package 9, failing which the corpora_te company shall take over from FGI, as may be demanded by the employer under this Guarantee, and shall perform or cause to be performed at its own cost and risk and all the responsibilities, obligations

G

H

312

SUPREME COURT REPORTS

¶321

[2017] 10 S.C.R.

¶322

A

¶323

A and duties of FGI under package 6 to Package 9 so far as and to the extent FGI was liable to perform it, without any additional time and cost implication to the employer, subject to the employer continuing to meet its own obligations under package 6 to package 9 with respect to payments, approvals for drawings and other related B matters to the corporate company as if the corporate company were the principal contractor in place of FGI.

¶324

In the event of any delay in completion of the works as per the time for completion of the contracts for the reasons attributable to FGI and/or the corporate company, such c that these delays in turn results in causing overall delay in completion of all or any one of the contracts, then the corporate company hereby undertakes to compensate for the delay damages to the employer, which shall be based on the overall contract price collectively of all the contracts D and any other contract that may be entered into by and between the employer and the corporate company or FGI .......... "

¶325

Content10n of GPL is that as per the Corporate Guarantee, the Spanish Company has inter alia undertaken to compensate GPL for E delay damages, based on the overall contract price collectively of all the Contracts awarded to both Duro Fclguera and FGI, arising on account of delay in completion of the works in any one or all of the five Contracts. It is contended that the Spanish Company is obligated to take over and perform the works at its own costs, risk and responsibilities, as if it is the Principal Contractor including for the works awarded to the Indian F Subsidiary and therefore as per terms of Corporate Guarantee executed by Duro Fclguera, there has to be a single arbitral tribunal for all the Packages.

¶326

As per the terms of Corporate Guarantee, it shall cease on issuance of the performance certificate under all the contracts. Of course, G Duro Felguera has given the Corporate Guarantee for all the five contracts viz., New Package No.4, Packages No. 6 to 9. Corporate Guarantee executed by Duro Felguera dated 17.03.2012 also recognizes the split up of the original Package No. 4 Tender Document. As per the terms of the Corporate Guarantee, it is to be invoked only if breach is H established in one of the five contracts. Since the Corporate Guarantee

¶327

313

¶328

MIS. DURO FELGUERA, S. A. v. M/S. GANGAVARAM PORT LIMITED [BANUMATHI, J.]

¶329

by itself has a separate arbitration clause, it cannot be contended that by virtue of the Corporate Guarantee executed by Duro Felguera, there has to be a 'composite reference' of 'International Commercial Arbitration' which would cover all the five Packages. The Corporate Guarantee hy Duro Felguera cannot supersede the five split-up contracts and the special conditions of contract thereon.

¶330

Duro Felguera and FGI have executed a tripartite Memorandum ofUnderstanding (MoU) on 11.08.2012 which, according to GPL, covers all the five contracts namely New Package No. 4, Package No. 6, Package No. 7, Package No. 8 and Package No. 9. In the said MoU both Duro Felguera and FGI have agreed to carry out the works as per the priority of the documents listed therein which includes the Original Package No.4 Tender Document issued and final bid submitted by Duro Felguera and FGI. The relevant portion of Memorandum of Understanding reads as under:-

A

B

c

"This Memorandum of Understanding (MoU) has been executed at Hyderabad on 11 •h August 2012 by and D between:

¶335

Mis Gangavaram Port Limited .....

¶336

And

¶337

Mis Duro Felguera Plantas lndusfries, S.A ....... .,

¶338

E

¶339

Mis Felguera Gruas India Private Limited ........

¶340

(Both DFPI and FGI shall jointly be referred to as the Contractors. The Employer and the contractors shall collectively be referred tQ as the Parties. All the captive F terms used if any herein shall have the same meaning ascribed to it in the Contract.)

¶341

Whereas the parties have entered into different package contracts for execution of Bulk Material Handling System under "Original Package 4 Tender Document" covering · ship unloaders, stackers, reclaimers, in-motion wagon G loading system, conveyors, transfer towers, electrical and control works, civil works, etc1 and in order to have more clarity on technical and execution related matters, the parties hereby agree that the works shall be carried out as per the following priority of documents. H

¶342

314

¶343

[2017] lOS.C.R.

¶344

SUPREME COURT REPORTS

¶345

A

¶346

Annexure I to the Letter of Award issued for Package 4 Contract.

¶347

Annexure III to the Letter of Award issued for Package 4, 6, 7, 8, and 9 contracts.

¶348

B

¶349

Clarifications/Addendum No.I to 4 (in the descending order) issued by the Employer to the Original Package 4 Tender Document.

¶350

The Original Package 4 Tender Document issued by the Employer.

¶351

c

¶352

Final Technical Bid submitted by the Contractors in response to the Original Package 4 Tender Document.

¶353

The parties undertake to keep this MoU as strictly confidential."

¶354

Contention of GPL is that Memorandum of Understanding

¶355

D (dated 11.08.2012) collectively covers all the five Packages and MoU shall prevail over the arbitration clauses contained in fi vc different Packages. In this regard, reliance was placed upon sub-section (5) of Section 7 of the Act to contend that since reference is made to Original Package No.4 TD in MoU, arbitration clause 20.6 must be deemed to have become part ofMoU. In support of their contention, learned Senior

¶356

E Counsel Mr. Mukul Rohatgi and Mr. Raju Ramchandran appearing for GPL, placed reliance upon Chloro Controls India Private Ltd. v. Severn Trent Water Purification Inc. and Others (2013) 1 SCC 641.

¶357

Per contra, the learned Senior Counsel for Duro Felguera and

¶358

FGI submitted that merely because MoU refers to Original Package

¶359

F No.4 Tender Document, such mere reference cannot lead to an inference of arbitration clause being incorpo,rated as it only depends upon the intention of the Pa11ies. It was further submitted that the Memorandum of Understanding (MoU) is merely a supplementary document which was meant to lay down the priority of documents only to clarify the

¶360

G priority in execution of the work under different Packages. It was further submitted that MoU was neither intended to alter the nature of the rights, responsibilities and obligafions of the parties involved in the respective contracts nor does it override the terms of the main contract including the arbitration clauses in the five different packages.

¶361

H

¶362

MIS. DURO FELGUERA, S. A. v. MIS. GANGAVARAM PORT 315 LIMITED [BANUMATHI, J.]

¶363

In light of the above contentions, the point falling for consideration is by virtue of sub-section (5) of Section 7, whether the MoU is to be taken as the basis for arbitration, justifying the constitution of single arbitral tribunal because a reference is made to Original Package No.4 TD in Memorandum of Understanding (MoU).

¶364

Section 7 (5) of the Arbitration and Conciliation (Amendment) Act, 2015 reads as under:-

¶365

A

¶366

B

¶367

"7. Arbitration agreeme11t.-(l) .....

¶368

(5) The reference in a contract to a document containing an arbitration clause constitutes an arbitration agreement if the contract is in writing and the reference is such as to make that arbitration clause part of the contract."

¶369

C

¶370

As per Section 7(5) of the Act, even though the contract between the parties does not contain a provision for arbitration, an arbitration clause contained in an independent document will be imported and engrafted in the contract between the parties, by reference to such independent D document in the contract, if the reference is such as to make the arbitration clause in such document, a part of the contract. Section 7(5) requires a conscious acceptance of the arbitration clause from another document, as a part of their contract, before such arbitration clause could be read as a part of the contract between the parties. The E question whether or not the arbitration clause contained in another' document, is incorporated in the contract, is always a question of construction of document in reference to intention of the pmiies. The terms of a contract may have to be ascertained by reference to more than one document.

¶371

F

¶372

In M.R. Engineers tind Contractors Private Limited v. Som Datt Builders Limited (2009) 7 SCC 696, the Supreme Court held that even though the contract between the parties does not contain a provision for arbitration, an arbitration clause contained in an independent document will be incorporated into the contract between the parties, by reference, if the reference is such as to make the arbitration clause in such document, a part of the contract. In M. R. Engineers and Contractors Private Limited (supra), this Court held as under:-

¶373

G

¶374

13 ........ Having regard to Section 7(5) of the Act, even though the contract between the parties docs not contain a provision for

¶375

H

¶376

316

¶377

SUPREME COURT REPORTS

¶378

[2017] JO S.C.R.

¶379

A

¶380

arbitration, an arbitration clause contained in an independent document will be imported and engrafted in the contract between the pa11ies, by reference to such independent document in the contract, if the reference is such as to make the arbitration clause in such document, a part of the contract.

B

c

D

A general reference to another contract will riot be sufficient to incorporate the arbitration clause from the referred contract into the contract under consideration. There should be a special reference indicating a mutual intention to incorporate the arbitration clause from another document into the contract. The exception to the requirement of special reference is where the referred document is not another contract, but a standard form of terms and conditions of trade associations or regulatory institutions which publish or circulate such standard terms and conditions for the benefit of the members or others who want to adopt the same.

¶385

The scope and intent of Section 7( 5) of the Act may therefore be summarised thus:

¶386

E

¶387

(i) An arbitration clause in another document, would get incorporated into a contract by reference, if the following conditions arc fulfilled:

¶388

(1) the contract should contain a clear reference to the documents containing arbitration clause,

¶389

F

¶390

G

¶391

(2) the reference to the other document should clearly indicate an intention to incorporate the arbitration clause into the contract,

¶392

(3) the arbitration clause should be appropriate, that is capable of application in respect of disputes under the contract and s~ould not be repugnant to any term of the contract.

¶393

(ii) When the parties enter into a contract, making a general reference to another contract, such general reference would not have the effect of incorporating the arbitration clause from

¶394

H

¶395

M/S. DURO FELGUERA, S. A. v. M/S. GANGAVARAM PORT LIMITED [BANUMATHI, J.]

¶396

317

¶397

c

¶398

the referred document into the contract between the parties. The arbitration clause from another contract can be incorporated into the contract (where such reference is made), only by a specific reference to arbitration clause.

¶399

A

¶400

(iii) Where a contract between the parties provides that the execution or performance of that contract ,shall be in terms of B another contract (which contains the terms and conditions relating to performance and a provision for settlement of disputes by arbitration), then, the terms of the referred contract in regard to execution/performance alone will apply, and not the arbitration agreement in the referred contract, unless there c is special reference to the arbitration clause also.

¶401

(iv) Where the contract provides that the standard form of terms and conditions of an independent trade or professional institution (as for example the standard terms and conditions ofa trade association or architects association) will bind them or apply to the contract, such standard form of terms and conditions including any provision for arbitration in such standard terms and conditions, shall be deemed to be incorporated by reference. Sometimes the contract may also say that the parties are familiar with those terms and conditions or that the parties have read and understood the said terms and conditions.

¶402

D

¶403

E

¶404

( v) Where the contract between the paiiie's stipulates that the conditions of contract of one of the parties to the contract shall form a part of their contract (as for example the general conditions of contract of the Government where the Government is a party), the arbitration clause forming part of F such general conditions of contract will apply to the contract between the parties."

¶405

Considering the MoU, in light of the above ratio, as pointed out earlier, in the MoU, Original Package No.4 Tender Document is merely referred only to have more clarity on technical and execution related matters and the parties agreed that the works shall be carried out as. per the priority of the documents indicated thereon. Mere reference to Original Package No.4 Tender Document in the sequence of priority of documents (as serial No.4) indicates that the documents Original Package No. 4 TD containing arbitration clause was not intended to be

G

H

318

SUPREME COURT REPORTS

¶410

[2017) IO S.C.R.

¶411

A incorporated in its entirety but only to have clarity in priority of the documents in execution of the work. Be it noted that Original Package No.4 TD occurs as Serial No.4 in sequence, after three other documents VIZ .. .,

¶412

"(i) Annexure I to the Letter of Award issued j(Jr Package

¶413

B No. 4 Contract: and (ii) Annexure fl! lo the Letter of Award issued for Packages No. 4, 6, 7, 8 and Y contracts; and (iii) Clarifications!Addendwns No. 1 to 4 (in the descending order) issued hy the Employer to the Original Package No. 4 Tender Document. "

¶414

c There are a number of contract agreements between the parties - GPL, Duro Felguera and FGI. It is pertinent to note that MoU dated 11.08.2012 itself does not contain an arbitration clause. When reference is made to the priority of documents to have clarity in execution of the work, such general reference to Original Package No.4 Tender Document will not be sufficient to hold that the arbitration clause 20.6 in the Original Package

¶415

D No.4 TD is incorporated in the MoU.

¶416

The submission of GPL is that since referene..: to Original Package No.4 TD is made in MoU, the arbitration dause is incorporated in th..: MoU and ther..: has to be a 'composite reference· for settling the disputes under different contracts by constitution of single arbitral tribunal E for dealing with the international commercial arbitration. As discussed earlier, as per the amended provision of sub-section (6A) of Section 11, the power of the court is only to examine the existence of arbitration agreement. When there are five separate contracts each having independent existence with separate arbitration clauses that is New F Package No.4 (with foreign company Duro Felguera) and Packages No. 6, 7, 8 and 9 [with Indian subsidiary (FGI)] based on MoU and Corporate Guarantee, there cannot be a single arbitral tribuna I for ''international Commercial Arbitration".

¶417

3 7. It was submitted that if the reque~t (1f GPL is accepted and all G Packages arc considered under the sam.: rdcr..:ncc, they shall be treated as international commercial arbitrations, then FGI may lose the opportunity of challenging the award under Section 34(2A) of th..: Act. In response to the above submission, GPL offered to concede and submitted that Section 34 (2A) of the Act may be invoked by Indian subsidiary-FG!, though Section 34(2A) is not applicable to international commercial

¶418

H

¶419

MIS. DURO FELGUERA, S. A. v. M/S.•GANGAVARAM PORT 319 LIMITED [BANUMATHI, J.]

¶420

arbitration. Such a concession is against the provisions and specific mandate of legislature and cannot be accepted.

¶421

A

¶422

The Corporate Guarantee dated 17.03.2012 was executed by the foreign company-Duro Felguera undertaking to compensate for the delay, damages to the GPL. Since the Corporate Guarantee was by the foreign company-Duro Felguera which contains separate arbitration clause, there has to be a separate arbitral tribunal for resolving the disputes arising out of the said Corporate Guarantee.

¶423

B

¶424

New Package No. 4 TD- F.O.B. Supply of Bulk Material Handling Equipments USD 26,666,932 has been awarded to the foreign company-Duro Felguera. Since Duro Felguera is a foreign company, in c so far as the contract awarded to Duro Felguera i.e. New Package No.4 and the dispute arising out of the Corporate Guarantee executed by the foreign company-Duro Felguera is concerned, the arbitral tribunal has to be for the international commercial arbitration.

¶425

The learned Senior Counsel for GPL relied upon Chloro Controls India Private Ltd. (supra), to contend that where various agreements constitute a composite transaction, court can refer disputes to arbitration if all ancillary agreements are relatable to principal agreement and performance of one agreement is so intrinsically interlinked with other agreements. Even though Chloro Controls has considered the doctrine of "composite reference", "composite performance" etc., ratio of Chloro Co11trols may not be applicable to the case in hand. In Cltloro Controls, the arbitration clause in the principal agreement i.e. clause ·(30) required that any dispute or difference arising under or in connection with the principal (mother) agreement, which could not be settled by friendly negotiation and agreement between the parties, would be finally settled by arbitration conducted in accordance with Rules of ICC. The words thereon "under and in connection with" in the principal agreement was very wide to make it more comprehensive. In that background, the performance of all other agreements by respective parties including third parties/non-signatories had to fall in line with the principal agreement. In such factual background, it was held that all agreements pertaining to the entire disputes are to be settled by a ''.composite reference". The case in band stands entirely on different· footing. As discussed earlier, all five different Packages as well as the Corporate Guarantee have separate arbitration clauses and they do not depend on the terms and conditions of the Original Package No.4 TD

D

E

F

G

H

320

SUPREME COURT REPORTS

¶433

[20 l 7J JO S.C.R.

¶434

A nor on the MoU, which is intended to have clarity in execution of the work.

¶435

Duro Felguera being a foreign company, for each of the disputes arising under New Package No.4 and Corporate Guarantee, International Commercial Arbitration Tribunai arc to be constituted. Mi B s. Duro Felguera has nominated Mr. Justice D.R. Deshmukh (Former Judge of Chhattisgarh High Court) as their arbitrator. Gangavaram Port Limited (GPL) has nominah:d Mr. Justice M.N. Rao (Former Chief Justice of Himachal Pradesh High Court). Alongwith the above two arbitrators Mr. Justice R.M. Lodha, Former ChiefJustice oflndia is appointed as the Presiding Arbitrator of the International Commercial c Arbitral Tribunal.

¶436

Package No.6 (Rs.208,66.53.657/-); Package No.7 (Rs.59,14,65,706/-); Package No.8 (Rs.9.94.38.6351-); and Package No.9 (Rs.29,52,85, 5581-) have been awarded to the Indian company-FOi. Since the issues arising between the parties are inter-related. the same D arbitral tribunal, Justice R.M. Lodha, Former Chief Justice oflndia, Justice D.R. Deshmukh, Former Judge of Chhattisgarh High ·Court and Justice M. N. Rao, Former Chit:f Justice of Himachal Pradesh High Court, shall separately constitl<IL Domestic Arbitral Tribunals for resolving each of the disputes pertaining to Packages No.6, E 7, 8 and 9.

¶437

Arbitration Petition No. 30 of 2016 filed by Duro Felguera shall stand allowed and Arbitration Petition No.31 of2016 filed by GPL shall stand disposed of in the same line. Transfer Case No. 25/2017, Transfer Case No. 26/2017, Transfer Case No. 2712017 and Transfer F Case No. 28/2017 filed by FGI shall also stand disposed of in the above lines. Parties shall bear their respective costs.

¶438

KURIAN, J.: I. While agreeing with the conclusions in the illuminating judgment of my esteemed sister Banumathi, J., I feel that a few more lines would add greater lustre to thl.' j •c1dgment.

¶439

G

¶440

What is the effect of the change introduced by the Arbitration and Conciliation (Amendment) Act, 2015 (hereinafter reforred to as .. the 2015 Amendment") with particular reference to Section 11(6) and the newly added Section I 1(6A) of the Arbitration and Conciliation Act. 1996 (hereinafter referred to as .. the 1996 Act") is the crucial question H arising for consideration in this case.

¶441

M/S. DURO FELGUERA, S. A. v. M/S. GANGAVARAM PORT 321 LIMITED [KURIAN, J.]

¶442

Section 11(6A) added by the 2015 Amendment, reads as A follows:

¶443

"11 ( 6A) The Supreme Court or, as the case may be, the High Court, while considering any application under sub-section ( 4) or sub-section ( 5) or sub-section ( 6), shall, notwithstanding any judgment, decree or order of any Court, confine to the B examination of the existence of an arbitration agreement."

¶444

(Emphasis Supplied)

¶445

From a reading of Section l 1(6A), the intention of the legislature is crystal clear i.e. the Court should and need only look into one aspectthe existence of an arbitration agreement. What are the factors for deciding as to whether there is an arbitration agreement is the next question. The resolution to that is simple - it needs to be seen if the agreement contains a clause which provides for arbitration pertaining to the disputes which have arisen between the parties to the agreement.

¶446

C

¶447

On the facts of the instant case, there is no dispute that there are five distinct contracts pertaining to five different works. No doubt c that all the works put together are for the expansion of facilities at Gangavaram Port. However, the pa1iies took a conscious decision to split the works which led to five separate contracts and consequently an arbitration Clause in each split contract was retained. The sixth one, namely the Corporate Guarantee also contains an arbitration clause.

¶448

D

¶449

E

¶450

The main thrust of the arguments of Mr. Mukul Rohatgi, learned Senior Counsel, is that the Memorandum of Understanding (hereinafter referred to as "MoU") has subsumed all the separate agreements and therefore and thereafter there can only be one agreement and, if so, only one Arbitral Tribunal for all the disputes emanating from the five different agreements and the Corporate Guarantee. This submission in our view is misconceived. The whole purpose of the MoU is evident from its text, the relevant portion of which has been extracted below:-

¶451

F

¶452

"Whereas the parties have entered into different package contracts for execution of Bulk Material Handling System under "Original Package 4 Tender Document" covering ship unloaders, stackers, reclaimers, in-motion wagon loading system, conveyors, transfer towers, electrical and control works, civil works, etc. and in order to have more clarity on technical and execution

¶453

G

¶454

H

¶455

322 SUPREME COURT REPORTS

¶456

[2017] IO S.C.R.

¶457

A related matters, the parties hereby agree that the works shall be carried out as per the following priority of documents:

¶458

Annexure I to the Letter of Award issued for Package 4 Contract.

¶459

B

¶460

Annexure Ill to the Letter of Award issued for Package 4, 6, 7, 8 and 9 contracts.

¶461

Clarifications/ Addendum No. 1 to 4 (in the descending order) issued by the Employer to the Original Package 4 Tender Document.

¶462

C 4. The Original Package 4 Tender Document issued by the employer.

¶463

Financial Technical Bid submitted by the contractors in response to the Original Package 4 Tender Document."

¶464

(Emphasis supplied)

¶465

D

¶466

It is clear that there is no novation by substitution of all the five agreements nor is there a merger of all into one. The reference to Original Package No. 4 Tender Document is only for better clarity on technical and execution related matters.

¶467

The above finding is wholly in line with Section 7(5) of the 1996 E Act. Section 7 which deals with arbitration agreement reads as follows:-

¶468

"7. Arbitration agreement.-( I) In this Part, "arbitration agreement" means an agreement by the parties to submit to arbitration all or certain disputes which have arisen or which may arise between them in respeti of a defined legal relationship,

¶469

F whether contractual or not.

¶470

(2) An arbitration agreement may be in the form of an arbit1:ation clause in a contract or in the form of a separate agreement.

¶471

(3) An arbitration agreement shall be in writing.

¶472

G ( 4) An arbitration agreement is in writing if it is contained in -

¶473

(a) a document signed by the parties;

¶474

H

¶475

(b) an exchange of letters, telex, telegrams or other means of telecommunication including communication through electronic means which provide a record of the agreement; or

¶476

M/S. DURO FELGUERA, S. A. v. M/S. GANGAVARAM PORT 323 LIMITED [KURIAN, J.]

¶477

(c) an exchange of statements of claim and defence in which A the existence of the agreement is alleged by one party and not denied by the other.

¶478

(filhe reference in a contract to a document containing an arbitration clause constitutes an arbitration agreement if the contract is in writing and the reference is such as to make that B arbitration clause part of the contract."

¶479

(Emphasis Supplied)

¶480

Section 7(5) deals with incorporation by reference. The words "the reference is such as to make that arbitration clause part of the contract" are of relevance. Essentially, the parties must have the intention to incorporate the arbitration clause. In M.R. Engineers and Contractors Pvt. Ltd. v. Som Datt Builders Ltd.¹ , Raveendran, J. has dealt with this particular requirement in a comprehensive manner. To quote:

¶481

"14. The wording of Section 7(5) of the Act makes it clear that a mere reference to a document would not have the effect of making an arbitration clause from that document, a part of the contract. The reference to the document in the contract should be such that shows the intention to incorporate the arbitration clause contained in the document, into the contract. If the legislative intent was to import an arbitration clause from another document. merely on reference to such document in the contract, sub-section (5) would not contain the significant later part which reads: "and the reference is such as to make that arbitration clause part of the contract", but would have stopped with the first part which reads:

c

D

E

F

"7. (5) The reference in a contract to a document containing an arbitration clause constitutes an arbitration agreement if the contract is in writing .... "

¶487

xxx xxx xxx

¶488

G

¶489

19. Sub-section (5) of Section 7 merely reiterates these wellscttled principles of construction of contracts. It makes it clear that where there is a reference to a document in a contract, and the reference shows that the document was not intended to be

1 (2009) 7 sec 696

H

324

SUPREME COURT REPORTS

¶494

(2017] I 0 S.C.R.

¶495

A incorporated in entirety, then the reference will not make the arbitration clause in the document, a part of the contract, unless there is a special reference to the arbitration clause so as to make it applicable.

¶496

xxx xxx

¶497

xxx

¶498

B 22. A general reference to another contract will not be sufficient to incomorate the arbitration clause from the referred contract into the contract under consideration. There should be a special reference indicating a mutual intention to incorporate the arbitration clause from another document into the contract. The exception to the requirement of special reference is where the c referred document is not another contract. but a standard form of terms and conditions of trade associations or regulatory institutions which publish or circulate such standard terms and conditions for the benefit of the members or others who want to adopt the same.

¶499

D

¶500

xxx xxx xxx

¶501

The scope and intent of Section 7(5) of the Act may therefore be summarised thus:

¶502

E

¶503

(i) An arbitration clause in another document, would get incorporated into a contract by reference, if the following conditions arc fulfilled:

¶504

(1) the contract should contain a clear reference to the documents containing arbitration clause,

¶505

F

¶506

(2) the reference to the other document should clearly indicate an intention to incorporate the arbitration clause into the contract,

¶507

(3) the arbitration clause should be appropriate, that is capable of application in respect of disputes under the contract and should not be repugnant to any term of the contract.

¶508

G

¶509

(ii) When the parties enter into a contract, making a general reference to another contract, such general reference would not have the effect of incorporating the arbitration clause from the referred document into the contract between the parties. The arbitration clause from another contract can be incomorated into

¶510

H

¶511

MIS. DURO FELGUERA, S. A. v. MIS. GANGAVARAM PORT 325 LIMITED [KURIAN, J.]

¶512

the contract (wheresuchreferenceismade),onlybya specific referencetoarbitration clause.	A
(iii)Where a contract between the parties provides that
the execution or performance of that contract shallbein
termsofanother contract (which contains the terms and
conditions relating to performance and a provision for	B
settlementofdisputes by arbitration), then, the termsof
the referred contractinregardtoexecution/performance alone will apply, and not the arbitration agreementinthe
referred contract, unless thereisspecial referencetothe arbitration clause also.	c
(iv)Wherethecontract provides that the standardformofterms andconditions ofanindependenttradeorprofessional institution
(asforexample the standardtermsandconditions of a trade association or architects association) will bind them orapplyto thecontract,suchstandardformoftermsandconditionsincluding anyprovisionforarbitrationinsuchstandardtermsandconditions, shallbedeemedtobeincorporatedbyreference. Sometimes	D
the contractmayalsosaythat the partiesarefamiliar withthose termsandconditionsorthatthepartieshavereadandunderstood the saidtermsandconditions.
(v)Where the contract between the parties stipulatesthatthe conditionsofcontractofoneofthe partiestothe contract shall formapartof theircontract(asforexamplethegeneralconditions ofcontract oftheGovernmentwheretheGovernmentisaparty),	E
thearbitration clauseformingpartofsuchgeneralconditions of contractwillapplytothecontract betweentheparties." (Emphasis supplied)	F

c

D

E

F

The detailed analysis of Section 7(5) in M.R. Engineers (supra) further fortifies our conclusion that the MoU does not incorporate . an arbitration clause.

¶518

Learned Senior Counsel also contended that for convenience, it is expedient that a single Arbitral Tribunal is constituted. We are afraid that this contention also cannot be appreciated. The parties arc free to agree to anything for their convenience but once suc'li tcnns arc reduced to an agreement, they can rcsilc from them only in accordance with law.

G

H

326

SUPREME COURT REPORTS

¶523

[20 I 7] IO S.C.R.

¶524

A 10. Having said that, this being one of the first cases on Section 11(6A) of the 1996 Act before this Court, I feel it appropriate to briefly outline the scope and extent of the power of the High Court and the Supreme Court under Sections 11(6) and l 1(6A).

¶525

This Court in S.B.P & Co v. Patel Engineering Ltd and B Another² overruled Konkan Railway Corpn. Ltd. and others v. Mehul Construction Co.³ and Konkan Railway Corpn. Ltd. & another. v. Rani Construction Pvt. Ltd.⁴ to hold that the power to appoint an arbitrator under Section I 1 is a judicial power and not a mere administrative function. The conclusion in tne decision as summarized by Balasubramanyan, J. speaking for the majority reads as follows:

¶526

c

¶527

"47. We, therefore, sum up our conclusions as follows:

¶528

(i) The power exercised by the Chief Justice of the High Court or the Chief Justice oflndia under Section 11 ( 6) of the Act is not an administrative power. It is a judicial power.

¶529

D (ii) The power under Section 11(6) of the Act, in its entirety, could be delegated, by the Chief Justice of the High Court only to another Judge of that Court and by the Chief Justice of India to another Judge of the Supreme Court.

¶530

(iii) In case of designation of a Judge of the High Court or of the E Supreme Court, the power that is exercised by the designated Judge would be that of the Chief Justice as conferred by the statute.

¶531

(iv) The ChiefJustice or the designated Judge will have the right to decide the preliminmy aspects as indicated in the earlier part of this judgment. These will be his own jurisdiction to entertain F the request. the existence of a valid arbitration agreement, the existence or otherwise of a Ii ve claim, the existence of the condition for the exercise of his power and on the qualifications of the arbitrator or arbitrators. The ChiefJustice or the designated Judge would be entitled to seek the opinion of an institution in the G matter ofnominating an arbitrator qualified in terms of Section I 1 (8) of the Act if the need arises but the order appointing the arbitrator could only be that of the ChiefJustice or the designated Judge.

G

'(2005J s sec 618

' (2000J 1 sec 201

H ·¹ (2002) 2 sec 388

¶536

M/S. DURO FELGUERA, S. A. v. M/S. GANGAVARAM PORT 327 LIMITED [KURIAN, J.]

¶537

( v) Designation of a District Judge as the authority under Section A 11 (6) of the Act by the Chief Justice of the High Court is not warranted on the scheme of the Act.

¶538

(vi) Once the matter reaches the Arbitral Tribunal or the sole arbitrator, the High Court would not interfere with the orders passed by the arbitrator or the Arbitral Tribunal during the course of the arbitration proceedings and the parties could approach the Court only in terms of Section 37 of the Act or in terms of Section 34 of the Act.

¶539

B

¶540

(vii) Since an order passed by the Chief Justice 9f the High Court or by the designated Judge of that Court is a judicial order, c an appeal will lie against that order only under Article 136 of the Constitution to the Supreme Court.

¶541

(viii) There can be no appeal against an order of the Chief Justice of India or a Judge of the Supreme Court designated by him while entertaining an application under Section 11 ( 6) of the Act. (ix) In a case where anArbitral Tribunal has been constituted by the parties without having recourse to Section 11(6) of the Act, the Arbitral Tribunal will have the jurisdiction to decide all matters as contemplated by Section 16 of the Act.

¶542

(x) Since all were guided by the decision of this Court in Konkan Rly. Corpn. Ltd. v. Rani Construction (P) Ltd. and orders under Section 11 ( 6) of the Act have been made based on the position adopted in that decision, we clarify that appointments of arbitrators oi· Arbitral Tribunals thus far made, are to be treated as valid, all objections being left to be decided under Section 16 of the Act. As and from this date, the position as adopted in this judgment will govern even pending applications under Section 11(6) of the Act.

¶543

(xi) Where District Judges had been designated by the Chief Justice of the High Court under Section 11(6) of the Act, the appointment orders thus far made by them will be treated as valid;, but applications ifany pending before them as on this date will stand transferred, to be dealt with by the ChiefJustice of the High Court concerned or a Judge of that Court designated by the Chief Justice.

D

E

F

G

H

[2017] IOS.C.R.

328

SUPREME COURT REPORTS

¶552

A (xii) The decision in Konkan Rly. Corpn. Ltd. v. Rani Construction (P) Ltd is overruled."

¶553

(Emphasis Supplied)

¶554

B

¶555

This position was further clarified in National Insurance Company Limited v. Boghara Polyfab Private Limited⁵ To quote:

¶556

"22. Where the intervention of the court is sought for appointment ofanArbitral Tribunal under Section 11, the duty of the Chief Justice or his designate is defined in SBP & Co. This Cou11 identified and segregated the preliminary issues that may arise for consideration in an application under Section 11 of the Act c into three categories, that is, ( i) issues which the Chief Justice or his designate is bound to decide; (ii) issues which he can also decide, that is, issues which he may choose to decide; and (iii) issues which should be left to the Arbitral Tribunal to decide.

¶557

22.1. The issues (first category) which the Chief Justice/his D designate will have to decide are:

¶558

(a) Whether the party making the application has approached the appropriate High Court.

¶559

(h) Whether there is an arbitration agreement and whether the party who has applied under Section l l of the Act, is a E party to such an agreement.

¶560

22.2. The issues (second categmy) which the Chief Justice/his designate may choose to decide (or leave them to the decision of the Arbitral Tribunal) are:

¶561

F (a) Whether the claim is a dead (long-barred) claim or a live claim.

¶562

(b) Whether the parties have concluded the contract/transaction by recording satisfaction of their mutual rights and obligation or by receiving the final payment without objection.

¶563

G

¶564

22.3. The issues (third category) which the Chief Justice/his designate should leave exclusively to the Arbitral Tribunal are:

¶565

(i) Whether a claim made falls within the arbitration clause (as for example, a matter which is reserved for final decision of a

¶566

H '(2009J 1 sec 261

¶567

MIS. DURO FELGUERA, S. A. v. MIS. GANGAVARAM PORT 329 - LIMITED [KURIAN, J.]

¶568

departmental authority and excepted or excluded from A arbitration). (ii) Merits or any claim involved in the arbitration."

¶569

The scope of the power under Section 11 (6) of the 1996 Act was considerably wide in view of the decisions in SBP and Co. (supra) and Boghara Polyfab (supra). This position continued till the amendment B brought about in 201 S. After the amendment, all that the Courts need to see is whether a~ arbitration agreement exists - nothing more, nothing less. The legislative policy and purpose is essentially to minimize the Court's intervention at the stage of appointing the arbitrator and this intention as incorporated in Section 11 ( 6A) ought to be respected. c

¶570

In the case at hand, there are six arbitrable agreements (five agreements for works and one Corporate Guarantee) and each agreement contains a provision for arbitration. Hence, there has to be an Arbitral Tribunal for the disputes pertaining to each agreemenL While the arbitrators can be the same, there has to be six Tribunals - two for D international commercial arbitration involving the Spanish CompanyM/s Duro Felguera, S.A. and four for the domestic.

¶571

Nidhi Jain

¶572

Matters disposed ot:

M/S. Duro Felguera, S. a. v. M/S. Gangavaram Port Limited

Case brief

What is this about?

What did the court decide?

M/S. Duro Felguera, S. a. v. M/S. Gangavaram Port Limited

Case brief

What is this about?

What did the court decide?

Why is it important?

What the court decided

Issues for consideration

Cases cited

Statutes considered

Procedural history

Parties & counsel

Coram

Case details

Similar cases

K. R. Babu versus State of Kerala & Ors.

Damini and Another versus Managing Director, Jodhpur Vidyut Vitran Nigam Limited and Another

Rima Taipodia versus Arunachal Pradesh Public Service Commission & Ors.

Santosh S/O Dwarkadas Fafat versus the State of Maharashtra

Life Insurance Corporation of India versus Sanjeev Builders Pvt. Ltd. and Ors.

Gujarat Urja Viikas Nigam Limited versus Solar Semiconductor Power Company (India) Private Limited and Others