Dismissed

In the matter of Ircon International Limited [Transfer Petition-15-ND-2022 in Company Petition No. (IB)-38-9-JPR-2021]

NCLT19 Oct 2023Transfer Petition-15-ND-2022 in Company Petition No. (IB)-38-9-JPR-2021

Case brief

AI extract

What is this about?

An operational creditor initiated a Corporate Insolvency Resolution Process against a corporate debtor alleging non-payment of a construction contract debt. The corporate debtor challenged the application, arguing a pre-existing dispute existed regarding work deficiencies and delays. The Bench found sufficient evidence of a pre-existing dispute, rejecting the application under the Insolvency and B

What did the court decide?

Transfer petition filed by applicant to initiate CIRP against respondent corporate debtor stands dismissed with no order as to costs.

In the matter of Ircon International Limited [Transfer… — Insolvency and Bankruptcy | NCLT (2023)

¶1

IN THE NATIONAL COMPANY LAW TRIBUNAL: NEW DELHI COURT – IV

¶2

Item No. 102 Transfer Petition/15/ND/2022 in CP IB/38/9/JPR/2021

¶3

IN THE MATTER OF: M/s NS Rolling Steel Private Limited … Applicant Versus Ircon International Limited … Respondent Order under Section 9 of IBC, 2016.

¶4

Order pronounced on 19.10.2023

¶5

CORAM: MR. MANNI SANKARIAH SHANMUGA SUNDARAM, HON’BLE MEMBER (JUDICIAL) DR. BINOD KUMAR SINHA, HON’BLE MEMBER (TECHNICAL) PRESENT: For the Applicant : For the Respondent : ORDER Order pronounced in open Court vide separate sheets.

¶6

Transfer Petition/15/ND/2022 in CP IB/38/9/JPR/2021 stands dismissed.

¶7

Sd/- Sd/DR. BINOD KUMAR SINHA MANNI SANKARIAH SHANMUGA SUNDARAM MEMBER (TECHNICAL) MEMBER (JUDICIAL)

¶8

IN THE NATIONAL COMPANY LAW TRIBUNAL NEW DELHI BENCH COURT-IV

¶9

TRANSFER PETITION/15/ND/2022 IN

¶10

COMPANY PETITION NO.(IB)-38/9/JPR/2021

¶11

Under Section 9 of the Insolvency and Bankruptcy Code, 2016 read with Rule 6 of the Insolvency and Bankruptcy (Application to Adjudicating Authority), Rules, 2016

¶12

IN THE MATTER OF:

¶13

M/s. NS ROLLING STEEL PRIVATE LIMITED

¶14

…. Applicant/ Operational Creditor

¶15

Vs.

¶16

M/s. IRCON INTERNATIONAL LIMITED

¶17

…. Corporate Debtor

¶18

Order Pronounced on: 19.10.2023

¶19

CORAM:

¶20

SH. MANNI SANKARIAH SHANMUGA SUNDARAM, HON’BLE MEMBER (JUDICIAL)

¶21

DR. BINOD KUMAR SINHA, HON’BLE MEMBER (TECHNICAL)

¶22

ORDER

¶23

PER: DR. BINOD KUMAR SINHA, HON’BLE MEMBER (TECHNICAL)

¶24

The instant application is filed by M/s. NS Rolling Steel Private Company, a private limited Company bearing CIN: U27106MH2008PTC187009 (hereinafter referred as ‘Applicant’/ ‘Operational Creditor’) under Section 9 of the Insolvency and Bankruptcy Code, 2016 (for brevity ‘the Code’) read with rule 6 of the Insolvency and Bankruptcy (Application to Adjudicating Authority) Rules, 2016 (for brevity ‘the Rules’) with a prayer to initiate

¶25

¶26

TRANSFER PETITION/15/ND/2022 IN

¶27

COMPANY PETITION NO.(IB)-38/9/JPR/2021 NS Rolling Steel Private Limited v. Ircon International Limited Date of Order: 19.10.2023

¶28

Corporate Insolvency Resolution Process in respect of M/s. IRCON International Limited (hereinafter referred as ‘Respondent Company’ or ‘Corporate Debtor’) for defaulting the payment of Rs.1,52,51,811/(Rupees One Crore Fifty Two Lacs Fifty One Thousand Eight Hundred Eleven Only) which includes principal amount of Rs.1,19,38,529/- and interest amount @24% p.a. amounting Rs.33,04,246/- .

¶29

The Respondent Company M/s. Ircon International Limited having CIN: L45203DL1976GOI008171 incorporated under the provisions of the Companies Act, 1956 is having its registered office situated at Plot No. C - 4, District Centre Saket, South Delhi, Delhi-110017. Since the registered office of the respondent corporate debtor is in New Delhi, this Tribunal having jurisdiction over the NCT of Delhi is the Adjudicating Authority in relation to the prayer for initiation of Corporate Insolvency Resolution Process in respect of respondent corporate debtor under sub-section (1) of Section 60 of the Code.

¶30

AVERMENTS BY THE APPLICANT

¶31

Succinctly stated facts of the present case as averred by the applicant are that the Corporate Debtor being a Government of India owned Railway construction company had allotted a contract work to the Applicant having the original contract value of Rs.5,74,28,000/-, in pursuance of the Tender issued by the Corporate Debtor and issued the work order dated 13.02.2018. Furthermore, the applicant had completed the work assigned to them on 12.06.2018 which is certified/approved by the site engineers as appointed by the Corporate Debtor.

¶32

The Applicant further submitted that the work was successfully completed by the Applicant in an effective and professional manner within the schedule time, therefore, the Applicant was awarded further contract work for an enhanced value of contract of Rs.9,37,81,874/-. The Applicant had 2

¶33

TRANSFER PETITION/15/ND/2022 IN

¶34

COMPANY PETITION NO.(IB)-38/9/JPR/2021 NS Rolling Steel Private Limited v. Ircon International Limited Date of Order: 19.10.2023

¶35

completed the total eligible gross work of Rs.9,37,81,874/- and the same has been approved and accepted by the Corporate Debtor which is also reflected in the Measurement Book of the Corporate Debtor and a letter dated 18.02.2020 was also issued by the DGM of the Corporate Debtor, acknowledging the same.

¶36

The Applicant submitted that the Applicant has received payment of Rs.7,94,33,018/and Rs.76,50,694/against the total work of Rs.9,37,81,874/-, thereby having an outstanding amount of Rs. 1,19,38,529/-. Also, the Corporate Debtor had after physical verification of the work done by the Applicant as per contract, had issued a completion certificate dated 05.02.2019.

¶37

It is also submitted that the Applicant had issued demand for the outstanding debt several times and also issued legal notices, however the outstanding amount was not paid by the Corporate Debtor despite the fact that the project was successfully completed by the Applicant. The Applicant had issued the Statutory Demand Notice dated 14.12.2020 under Section 8(1) of the Code, 2016 demanding the outstanding amount of Rs.1,52,51,811/- inclusive of an interest @ 24% p.a.. The Corporate Debtor in reply to the Demand Notice dated 14.12.2020 had raised the issue that the work is not completed by the Applicant, though in fact work is completed by the Applicant and the same is evidenced from the Completion Certificate issued by the Corporate Debtor after verification.

¶38

REPLY BY THE CORPORATE DEBTOR

¶39

On notice by this Adjudicating Authority, the Corporate Debtor had filed its reply and submitted that the Corporate Debtor is an undertaking of the Government of India incorporated under the Companies Act, 1956 and is

¶40

¶41

TRANSFER PETITION/15/ND/2022 IN

¶42

COMPANY PETITION NO.(IB)-38/9/JPR/2021 NS Rolling Steel Private Limited v. Ircon International Limited Date of Order: 19.10.2023

¶43

a leading turnkey construction company in the Public Sector, specializing in railway and highway constructions.

¶44

The Corporate Debtor submitted that on 30.01.2019, vide letter No. NSRS/LH/18-19/220, the Applicant had requested for issuance of work completion certificate ("Work done certificate") for the purpose of submitting it to the Ministry of Road Transport and Highway, Government of India ("MOR&TH") for participation in their tender process. It is pertinent to note that the work had not been completed at this stage. Accordingly, on 05.02.2019, ‘Work done certificate’ was issued by the Corporate Debtor vide Letter No. IRCON/1034/BPHP/NH-15/82, specifically mentioning that the work was in progress in the extended period. Further, it was mentioned that the Work done certificate was issued upon a specific request of the Applicant for purpose of participation in the tender only process and have no obligations under any contract conditions under the above-mentioned contract agreement. This certificate was not issued in terms of Clause-65 of the General Conditions of the Contract ("GCC") and the Contractor had also not requested to issue completion certificate in terms of the said clause as the work was not completed till that time.

¶45

The Corporate Debtor further submitted that the Applicant has deliberately attempted to mislead, by claiming the ‘work done certificate’ to be the work ‘completion certificate’. The correct fact is that completion certificate has to be issued as per Clause-65 of the GCC, whereas, till date the Applicant has not even submitted the application/notice for issuance of the Work Completion Certificate as per Clause-65 of the GCC. Further, Clause-65.1 and 65.2, clearly stipulate that, “if any kind of deficiencies/ defects are noticed in the work carried out by the Contractor, then the same shall have to be rectified by the Contractor and further in the event of default by the Contractor in carrying the rectification works, then

¶46

¶47

TRANSFER PETITION/15/ND/2022 IN COMPANY PETITION NO.(IB)-38/9/JPR/2021 NS Rolling Steel Private Limited v. Ircon International Limited Date of Order: 19.10.2023

¶48

IRCON shall be entitled to recover any money due to the contractor under the contract, including the performance security amount or any money payable to the Contractor.”

¶49

10.Furthermore, it was submitted that the Corporate Debtor had duly communicated various defects / deficiencies in the work, which has not been rectified till date. Also, the Applicant had sent a legal notice dated 21.01.2020, to which the Corporate Debtor had replied vide its response dated 19.02.2020, which clearly shows that there exists a pre-existing dispute between the parties, with regard to the alleged outstanding amount, claimed by the applicant. Also, the alleged due amount is not at all due and payable to the Applicant and therefore, cannot be construed to be an operational debt in the eyes of law and consequently, no default can be alleged against the Corporate Debtor.

¶50

ANALAYSIS AND FINDING

¶51

11.We have heard the Ld. Counsels for the parties and perused the averments made in the application, reply, rejoinder and written submissions filed by the parties. The relevant documents annexed with the respective submissions have been perused.

¶52

12.Adverting to the facts of the present case, IRCON International Limited awarded tender No. IRCON/1034/BPHP/TN/ NITET-139/WBM/CB/159 to the Contractor for "Providing, Supplying, Erecting and Fixing in Position "W" Beam Metal crash barrier system single sided/single row including fish tail Single Terminal unit as per MORT&H specifications and the work was to be completed within four (4) months, i.e., by 12.06.2018. However, the Applicant on 19.06.2019, vide Letter NSRS/LH/19-072, had requested for an extension of time for further one month to complete balance work without penalty.

¶53

¶54

TRANSFER PETITION/15/ND/2022 IN

¶55

COMPANY PETITION NO.(IB)-38/9/JPR/2021 NS Rolling Steel Private Limited v. Ircon International Limited Date of Order: 19.10.2023

¶56

13.From the records as placed before this Adjudicating Authority, we observe that a meeting was also held between parties on 29.06.2019 wherein the following issues i.e., (i) Progress of Work, (ii) extension of time for Balance Works, (iii) Delay in getting payment against bill, (iv) Release of withheld amount, (v) Completion of Punch list items and (vi) Execution of concrete foundation work were discussed between the parties. The relevant extract from the minutes of the meeting dated 29.06.2019 is reproduced below:-

¶57

(Extract from the minutes of the meeting dated 29.06.2019)

¶58

¶59

TRANSFER PETITION/15/ND/2022 IN

¶60

COMPANY PETITION NO.(IB)-38/9/JPR/2021 NS Rolling Steel Private Limited v. Ircon International Limited Date of Order: 19.10.2023

¶61

14.A perusal of the minutes of the meeting dated 29.06.2019 held between the parties, clearly shows that the Corporate Debtor had raised concern over the non-completion of the work within the extant timeline and also highlighted the deficiencies in the work of the Applicant. Also, the Corporate Debtor had placed on record their letter dated 16.12.2019 issued by the Corporate Debtor to the Applicant wherein the Applicant was informed that the full depth foundation concrete had not been executed and was advised to carry out the foundation rectifications as per drawing & specification, so that after verification, the payment, if eligible, would be released. The Corporate Debtor had placed on record the letters dated 27.02.2020, 06.03.2020, 12.03.2020, 01.06.2020, and 09.06.2020 wherein the claims and demand of the Applicant were disputed and denied by the Corporate Debtor on account of delay in completion of works within original Completion time as well as the failure in rectification of the deficiencies as raised by the Corporate Debtor.

¶62

15.With regard to the Work Done Certificate dated 05.02.2019 as relied upon by the Applicant, we observe that the work done certificate dated 05.02.2019, was issued by Corporate Debtor vide Letter No. IRCON/1034/BPHP/NH-15/82, wherein, against the point no.8 for denoting the ‘Actual Completion Date’, it was specifically mentioned that, “the work was in progress in the extended period” and that the ‘Work done certificate’ was issued upon a specific request of the Applicant for the purpose of participation in the tender and without any obligation of the Corporate Debtor.

¶63

16.Further, it is the contention of the Corporate Debtor, that the Work Completion Certificate as per Clause-65 of the GCC, could be issued only after rectification of deficiencies and removal of defects by the Operational Creditor, however from the material placed on record, we observe that the

¶64

¶65

TRANSFER PETITION/15/ND/2022 IN

¶66

COMPANY PETITION NO.(IB)-38/9/JPR/2021 NS Rolling Steel Private Limited v. Ircon International Limited Date of Order: 19.10.2023

¶67

applicant had failed to rectify the defect/deficiencies in the work which has been communicated to the Applicant by the Corporate Debtor. Accordingly, this Adjudicating Authority is of the view that the ‘Work Done Certificate’ dated 05.02.2019 as relied upon by the Applicant cannot be considered as conclusive evidence of either the factum of satisfactory completion of work by Corporate Debtor or for establishing that there exists no pre-existing dispute between the parties, particularly in the absence of a ‘work completion certificate’ issued in terms of clauses 65.1 & 65.2 of GCC.

¶68

17.It is pertinent to note that this Adjudicating Authority must not be oblivious to the limited nature of examination of the case of the Corporate Debtor projecting a pre-existing dispute and shall not overlook the boundaries of this Adjudicating Authority’s jurisdiction while determining the question of existence of pre-existing dispute between the parties.

¶69

18.In the instant case, the Corporate Debtor has brought on record by way of its reply to the instant application, material to indicate pre-existence of dispute and we are of the considered view that there is sufficient evidence on record to exhibit a ‘Pre-Existing Dispute’ between the parties prior to the issuance of the Demand Notice under Section 8 (1), IBC, 2016.

¶70

19.Further, the defence of the Corporate Debtor is not spurious, mere bluster, plainly frivolous or vexatious. It is also important to note that the Hon’ble Supreme Court in Rajratan Babulal Agarwal vs Solartex India Pvt. Ltd. & Ors. [Civil Appeal No. 2199 of 2021] had observed that when we speak about evidence of pre-existing dispute, we must not overlook the law laid down in Mobilox Innovations Private Limited v.

¶71

Kirusa Software Private Limited [(2018) 1 SCC 353] wherein it was observed that, “the court need not be satisfied that the defence is likely to succeed. The standard, in other words, with reference to which a case of a

¶72

¶73

TRANSFER PETITION/15/ND/2022 IN

¶74

COMPANY PETITION NO.(IB)-38/9/JPR/2021 NS Rolling Steel Private Limited v. Ircon International Limited Date of Order: 19.10.2023

¶75

pre-existing dispute under the IBC must be employed cannot be equated with even the principle of preponderance of probability which guides a civil court at the stage of finally decreeing a suit.”

¶76

20.In the same judgement in Mobilox (supra), Hon’ble Supreme Court have categorically laid down the following criteria for determination of admissibility of a Section 9 Application in Para 34 as under:

¶77

“34. Therefore, the adjudicating authority, when examining an application under Section 9 of the Act will have to determine:

¶78

(i) Whether there is an “operational debt” as defined exceeding Rs 1 lakh? (See Section 4 of the Act)

¶79

(ii) Whether the documentary evidence furnished with the Application shows that the aforesaid Debt is due and payable and has not yet been paid? and

¶80

(iii) Whether there is existence of a dispute between the parties or the record of the pendency of a suit or arbitration proceeding filed before the receipt of the demand notice of the unpaid operational Debt in relation to such dispute?

¶81

If any one of the aforesaid conditions is lacking, the Application would have to be rejected. Apart from the above, the adjudicating authority must follow the mandate of Section 9, as outlined above, and in particular the mandate of Section 9(5) of the Act, and admit or reject the Application, as the case may be, depending upon the factors mentioned in Section 9(5) of the Act.”

¶82

21.Since, we have already held hereinabove that there exists a ‘pre-Existing Dispute’ between the Applicant and the Corporate Debtor, the instant application is liable to be rejected.

¶83

22.Accordingly, the instant petition Transfer Petition/15/ND/2022 in C.P. No./38/9/JPR/2021 stands dismissed with no order to costs.

¶84

Let copy of the order be served to the parties. Consign the file to the record room.

¶85

Sd/- Sd/(DR.BINOD KUMAR SINHA) (MANNI SANKARIAH SHANMUGA SUNDARAM) MEMBER (T) MEMBER (J)

¶86

¶87

TRANSFER PETITION/15/ND/2022 IN

¶88

COMPANY PETITION NO.(IB)-38/9/JPR/2021 NS Rolling Steel Private Limited v. Ircon International Limited Date of Order: 19.10.2023

In the matter of Ircon International Limited [Transfer Petition-15-ND-2022 in Company Petition No. (IB)-38-9-JPR-2021]

Case brief

What is this about?

What did the court decide?

In the matter of Ircon International Limited [Transfer Petition-15-ND-2022 in Company Petition No. (IB)-38-9-JPR-2021]

Case brief

What is this about?

What did the court decide?

What the court decided

A compact analysis

Issues for consideration

Cases cited

Statutes considered

Parties & counsel

Coram

Case details

Similar cases